HomeMy WebLinkAbout1235 - West Const Surety Bd�11 AL C j
0 ?'��
Gj 23 EGANFUSKEE STREET
3r
a SUITE 102
tz
JUPITER, FL 33477
INC TELEPHONE (561) 776 -9001
FAcsIMILE (561) 427 -6730
Building Relationships www.calinc.com
August 14, 2008
City of Sanford, FL
300 North Park Avenue
Sanford, FL 32771
RE: West Construction, Inc.
Fort Mellon Park Reconstruction Project, Phase 1
Project No. IFB 07/08 -10
To whom it may concern:
This letter will serve as Western Surety Company's authority for City of Sanford to date
the Performance, the Payment Bond and the necessary Power of Attorney for the above
captioned.
We acknowledge this must be handled in this manner, as the necessary forms must be
filed with Palm Beach County prior to the physical execution of the contract.
Yours truly,
0
t ,
D. Michael Stevens
Attorney -in -Fact
Western Surety Company
II ALT
LO
Gj
23 EGANFUSKEE STREET
QM
ty
SUITE 102
JUPITER, FL 33477
C�
INC
TELEPHONE (561) 776 -9001
Q
FACSIMILE (561) 427 -6730
cv
Building Relationships
www.calinc.com
Contract No.: IFB 07/08 -10
Surety Bond No.:
58655214
Contractor Name: West Construction, Inc.
Surety Company:
WESTERN SURETY COMPANY
Address: 318 South Dixie Highway Suite 4 -5
Address:
2405 LUCIEN WAY
Lake Worth, Florida 33460
MAITLAND, FLORIDA 32751
Phone Number: 561/588 -2027
Phone Number:
407/919 -2260
Owner Name: City of Sanford
Project Name:
Fort Mellon Park Reconstruction
Proiect, Phase 1
Address: 300 North Park Avenue
Project Location:
600 East 1 Street
Sanford, Florida 32771
Sanford, FL
Phone Number: 407 - 688 -5000 x5423
Contract Amount: Four Million Four Hundred Four Thousand Five Hundred One and 85 /100 -- Dollars
Description of Work: General Construction Services — Fort Mellon Park Reconstruction Proiect Phase 1
Legal Description of Project: "see attached legal description"
This bond is given to comply with section 255.05 Florida Statutes and any action instituted by a claimant
under this bond for payment must be in accordance with the notice and time limitation provisions in
Section 255.05(2), Florida Statutes. Any provision of this bond which conflicts with or purports to grant
broader or more expanded coverage in excess of the minimum requirements of the applicable statute shall
be deemed deleted herefrom. This bond is a statutory bond, not a common law bond.
This is the front page of the performance /payment bond(s) regardless of preprinted numbers on other
pages issued in compliance with Florida Statute 255.05.
A PARCEL OF LAND L YING I N SECT70N 30, ro#NSHIP 19 SOUTH, RANGE
BEING DESCRIBED AS FOLLO#S;-
BEGYN A THE NORTH#ST OF LOT 48, LAKEKL - )� PARK
ACCORDING TO 7HE PLAT THEREOF,,44S RECORDED IN PLAT (BOOK 5,
PAGE 41, PUBLIC RECORDS OF SEM/NOLE COUNTY, FLORIDA FOR A
PoINr OF BEGINNING, SAID POINT ALSO BEING THE INTE RSEC77oN OF
THE EAST RIGHT -OF 0 Y LINE OF SANFORD A VENUE AND WE
SOUTHERL Y R/GH7 -0E- f f Y LINE OF SEVINOLE BOULEVARO, THENCE
RUN, SOUTH 69Y6,:21" EAST ALONG SAID SoUTHERL Y RIGHT --OF- jf *A Y
LINE, 386.26 FEET r0 THE PClNT OF CURVATURE OF A CURVE' CONCAVE"
NORMEASTERZY,• THENCE RUN SOUTNEA57ERLY ALONG SAID CURVE
HAVING A RADIUS OF 281636 FEET A CENTRAL ANGLE OF 08'1628; AN
ARC LENGTH OF 40837 FEET A CHORD LENGTH OF 408,01 FEET AND A
CHORD BEARING OF SOUTH 73. 636" EAsr To THE NoRT #ur
CORNER OF LOT 29, BLOCK "A ; FIRST STREET EXTENSION ACCORDING
70 THE Pt A r THEREOF AS RECORDED IN PL r BOOK T, PAGES 76 AND
76 -A OF SAID PUBLIC RECORDS AND THE CENTERLINE OF "PUMP
BRANCH" ACCORDING TO SAID PLA r OF FIRST STREET EXTENS/ON,
THENCE RUN THE FOLLOANG COURSES ALONG 7HF ST LINE OF
SAID BLOCK " A " AND THE CENTERLI OF SAID "PUVP BRANCH"..
SOUTH 10 56'19" EAsr, 9741 FEET; SOUTH 1144'18" EAST, 76,13 FEET,•
SOUTH 09'13'10" EAST, 6860 FEET; SOUTH 1251'32" EAST, 16.39 FEET,•
SOUTH 07'68'11" E4sr foo.98 FEET to 7HE SOUTH LINE' OF 7HE
AFORESAID BLOCK "A" AND 77iE NORTH R /GHT- of -*A Y LINE of FIRST
sTREEr,• THE RuN, NORTH 9000'00" #E ALONG SAID NORTH
RIGHT- Y LINE, 81517 FEET ro ME AFORESAID E RIGHT -
�kAY LINE OF SANFORD AW&U • THENCE RU NORTH 00'11023" EAST
ALONG SAID EAST RlcH -oF -)AY LIAF, 60784 FEET ro 7HE POINT OF
BEGINN /N6
78 BOYE DESCRIBED PARCEL OF LAND LIES IN THE QTy OF SANFORD,
S ' 90 FLORID AND CONTAINS 8.409 FEET ACRES, MORE OR LESS
r V
V
A PARCEL OF LAND LYING /N SEC77ON 30, 7006HIP 19 SOUTH, RANGE
EAST BEING DESCRIBED AS F0110ft
EAST
SEMY A r 7HE NORTH. j EST CORNER OF LOT 29, BLOCK "A", FIRST STREET
EYMNSION, ACCORDING r0 THE PLAT THEREOF AS RECORDED ! �/�I PLAT
BooK 3, PAGES 76 AND 76A OF THE PUBLIC RECORDS OF SEM/NOLE
COUNTY �� FLORIDA, ALSO BEING ON THE SOUTHERLY RIGHT - -OF #AY LINE
OF Si9lW&E BOULEVARD ACCORDING TO SAID PLAT OF FIRST STREET
MENS /0N AND BEING A POINT ON A CURVE CONCAJam' NORMEASTSMY,
THENCE RUN SOUTNEAS7FRLY ALONG SAID CURVE AND SAID
SOUTHERLY R /GHT- OF -#A.Y LINE, HA KNG A RAD /US of 281636 FEET, A
CENTRAL ANGLE OF 01'16'31 AN ARC LENGTH OF 61.87 FEET A CHORD
LENGTH OF 61,87 Er, AND A CHORD BEARING OF SOUTH 7812 EAS
TO A Po/Nr OF COgPoUND CURVATURE OF A CURVE CONCAVE'
NOR7HEAS7ERL Y THENCE RUN SOUTNE Y AL ONG SAID CURVE
AND SAID Sowwa Y RIGHT = of - -ykA Y LINE HAKNG A RADIUS OF 6782.80
FEET, A CENTRAL ANGLE OF 102617; AN ARC LENGTH of UJXX72 FEET,
CHORD LENGTH OF 1232.02 FEET, AND A 6HCRD BEARING OF
SOUTH 84'02'59" EAST ro 7NE NORTHEAST CORNER of LOT 9, BLOCK "D"
OF SAID PLAT OF nRSr srwr £X7FNS/ok THENCE RUN,
SOUTH 04'19'64" #EST ALONG THE EAST LINE OF SAID BLOCK "O", 293
FEET TO 7HE SOUTHEAST CORNER OF LOT 10 of SAID BLOCK "D ALSO
BEING THE NOR 77-1 RIGHT -OF #AY LINE OF f7RSr STREET; ACCORDING TO
SAID PLA r OF FIRST S7REE EX7EA(sloAr THENCE RUN ALONG SAID
NORTH R16H OF AY LINE THE FOLLO fNG COURSES'
NORTH 8454'01" #M,, 87643 FEET,• NORTH 90710'00" #rsr, 329.07 FEE 70
7NE sou;w Esr CORNER OF LOT 12 of Thr AFORESAID BLOCK "A , FIRST
STREET EXTENSION THENCE RUN ALONG THE Sr uft OF SAID BLOCK
"A" 771E FOLLO COURSES; NORM 0768'11. " {f£ST, 100.98 FEET;
NDR7H 12151'32" #f 1639 FFEr, NO RTH 09 1370" #EST, 6860 FEET;
NO P 1N '1 BED 1G.813 FEET, NORIN 10'68'19" jfEST, 97.41 FEET T
THE ABOW' DESCRIBED PARCEL OF LAN LIE IN SEINOLE oouN
fzoRIDA AND caNrAINS 8 ACRES MORE OR LESS.
SECTION 00605
Bond No. 58655214
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
West Construction, Inc.
(Name of CONTRACTOR)
318 South Dixie Highway, Suite 4 -5 Lake Worth, Florida 33460
(Address of CONTRACTOR)
a Florida , hereinafter called
(Corporation, Partnership or Individual)
Principal, and Western Surety Company
(Name of Surety)
2405 Lucien Way, Maitland, Florida 32751
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto 1) city of Sanford FL
hereinafter called ) OWN i t e full.and just Sum of Four Million Four Hundred Four Th ousand
� p
Fi ve Hundred One an 'XL S f$ 4,404,501.85 ) in lawful money of the
United States, for the payment of which sum well and truly to be made, we bind ourselves,
successors, and assigns, jointly and severally, firmly by these presents. The sum shall not be
less than one hundred ten percent (110 %) of the Contract Price,
THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a
certain Agreement with the OWNER, dated the day of
�_, a copy of which is hereto attached and made a part hereof for the construction of 2)___
Fort Mellon Park Reconstruction Project, Phase 1
9) Name of Owner
2) Name of Profeot identtffed In Instructions to Bidders
This bond Is being entered Into to satisfy the requirements of Section 255.05, Florida Statutes.
and the Agreement referenced above, as the same may be amended.
The Surety shall be bound by any and all alternative dispute resolution awards and settlements
to the same extent as CONTRACTOR is bound.
NOW, THEREFORE, the condition of this obligation is such that if Principal:
1. Promptly and faithfully performs its duties, all the covenants, terms, conditions,
and agreements of said Agreement including, but not limited to the insurance
provisions, guaranty period and the, warranty provisions, in the time and manner
prescribed in the Agreement, and
006051
2. Pays OWNER. all losses, damages, delay damages (liquidated or actual),
expenses, costs and attorneys' fees, including costs and attorney's fees on
appeal that OWNER sustains resulting directly or indirectly from any breach or
default by Principal under the Agreement, and
3. Satisfies all claims. and demands incurred under the Agreement, and fully
indemnifies and holds harmless the OWNER from all costs and damages which it
may suffer by reason or failure to do so, then this bond is void; otherwise It shall
remain in full force and effect.
The coverage of this Performance Bond is co -equal with each and every obligation of
the Principal under the above referenced Agreement and the Contract Documents of which the
Agreement is a part.
In the. event that the Principal shall fall to perform any of the terms, covenants and
conditions of the Agreement and the Contract Documents of which the Agreement is a pant
during the period in which this Performance Bond is in effect, the Surety shall remain liable to
the OWNER for all such loss or damage.
In the event that the Surety fails to fulfill its obligations under this Performance Bond,
then the Surety shall also Indemnify and hold the OWNER harmless from any and all loss,
damage, cost and expense, including reasonable attorneys' fees and costs for all trial and
appellate proceedings, resulting directly or indirectly from the Surety's failure to fulfill its
obligations hereunder. This subsection shall survive the termination or cancellation of this
Performance Bond.
The Surety stipulates and agrees that its obligation is to perform the Principal's work
under the Agreement under the Bond.. The following shall not be considered performance under
the Bond: (1) Surety's financing of the Principal to keep Principal from defaulting under the.
Contract Documents, (ii) Surety's offers to OWNER to buy back the Bond, and (iii) Surety's
election to do nothing under the Bond shall be construed as a material breach of the Bond and
bad faith by the Surety. The Surety agrees that its obligation under the bond is to: (i) take over
performance of the Principal's Work and be the completing Surety even if performance of the
Principal's Work exceeds the Principal's Contract Price or (ii)re -bid and re -let the Principal's
Work to a completing contractor with Surety remaining liable for the completing contractor's
performance of the Principal's Work and furnishing adequate funds to complete the Work. The
Surety. acknowledges that its cost of completion upon default by the Principal may exceed the
Contract Price. In any event, the Principal's Contract Time is of the essence and applicable
delay damages are not waived by OWNER.
The Surety, for value received, hereby stipulates and agrees that its obligations
hereunder shall' be direct and immediate and not conditional or contingent upon OWNER's
pursuit of its remedies against Principal, shall remain in full force and effect notwithstanding (1)
amendments or modifications to the Agreement entered into by OWNER and Principal without
the Surety's knowledge or consent (li) waivers of compliance with or nay default under the
Agreement granted by OWNER to Principal without the Surety's knowledge or consent, or (ill)
the discharge of Principal from its obligations under the Agreement as a result of any
proceeding initiated under the Bankruptcy Code of 1978, as the same may be amended, or any
similar state or federal law, or any limitation of the liability or Principal or its estate as a result of
any such proceeding.
00605 -2
Any changes in or under the Agreement and Contract Documents and compliance or
noncompliance with any formalities connected 'with the Agreement or the changes therein shall
not affect Surety's obligations under this Bond and Surety hereby waives notice of any such
changes. Further, Principal and Surety acknowledge that the Sum of this Bond shall increase or
decrease in accordance with Change Orders (unilateral and bilateral) or other modifications to
the Agreement and Contract Documents,
The Performance Bond and the Payment Bond and. the covered amounts of each are
separate and distinct from each other.
This Bond is intended to comply with the requirements of Section 255.05, Florida
Statutes, as amended, and additionally, to provide common law rights more expansive than as
required by statute, The Surety agrees that this Bond shall be construed as a common law
bond.
IN WITNESS WHEREOF, this instrument is executed this the — day of
Secret rincipal)
Matthew F. West, Secretary
Typed Name
(CORPORATE SEAL)
(Witness to Principal)
Typed Name
ATTEST:
as per attached power of attorney
(Surety) Secretary
Typed Name
( - PORAT EAL)
� 00605 -3
West Construction, Inc.
Principal (Contr for
By (Signature)
Martha A. Morgan, President
Typed Name and Title
3 18 South Dixie Highway - Suite 4 - 5
Address
Lake Worth, Florida .33460
City, State, Zip
561/588 =2027 561/588 -9419
Telephone No. Facsimile No.
Western Surety Company
Surety
877/276 - 7511 605/330 -7416
Telephone No. Facsimile No.
B �-
t✓
Witness as to Surety
Olga Rodrigue
Typed Namp
���
Witness as to Surety
Melinda Rosenhaus
Typed Name• . -
Attorney -in -Fact
D. Mic hae l S teven s ,
Typed Name
2405 Lucien Way
Address
_Maitland, Florida 32751
City, State, Zip
877/276 -7511 6 05/330 -7416
Telephone No. Facsimile No.
NOTE: Date of the Bond must not be prior to date of Agreement. If CONTRACTOR is a Joint
venture, all venturers shall execute the Bond. If. CONTRACTOR is partnership, all partners
shall execute the Bond.
IMPORTANT: Surety companies executing Bonds must appear on the Treasury Department's
most current list (Circular 570 as amended) and be authorized to transact business in the State
of Florida,. unless otherwise specifically approved 6 writing by OWNER.
ATTACH a certified Power -of- Attorney appointing individual Attorney -in -Fact for execution of
Performance Bond on behalf of Surety.
END OF SECTION
00605 -4
Western Surety Company
POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -fN -.FACT
Know'All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and exi
having its principal office in the City of Siou sting corporation
x Falls, and State of South Dakota, and that it does by virtue of the si
make, constitute and appoint gnature and seal herein affixed hereby
Don A Lambert Jr, D Michael Stevens, Individually
of Palm Beach Gardens, FL, its true and lawful Attorneys) -in -Fact with full power and authority hereby conferred to sign, seal and execute for
and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - for any and all'surety
bonds and any and all consents required by the State Department of Transportation of the State of Florida, incident to the release of retained
percentages and /or estimates on engineering and /or construction contracts - and to bind it thereby as fully and to the same extent as if such
instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority ' hereb y
given, are hereby ratified and confirmed.
This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by
the shareholders of the corporation.
In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to
be hereto affixed on this 24th day of October, 2006.
WESTERN SURETY COMPANY
r c s
. , Senior Vice President
State of South Dakota Paul Bruflat
County OfMinnehaha ss
On this 24th day of October, 2006, before me personally came Paul T. Bruflat, to me known, who, being by me duly swom, did depose and say: that
he resides in the City of Sioux Falls, State of South Dakota; that he, is the Senior Vice President of WESTERN SURETY COMPANY described in and
Which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was
i
so affixed pursuant to authorty given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and
acknowledges same to be the act and deed of said corporation.
My commission expires + ssasSasssss5sssssti5ati5as +
r
r
D. KRELL r
r
November30, 2012 N
r OTARY PUBLIC � i
r SEAL SOUTH DAKOTA 3y-- i
r r
+SSS SSaSS 55, ss5tittiasss5 5 +
CERTIFICATE D. Krell, No ary Public
I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in
force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed
my name and affixed the seal ofthe said corporation this
day of
-
=y �?F' WESTERN SURETY COMPANY
y c,�� pOggl F{➢ -
*€ %S1
s t
p'�?- w
SECTION 00610
PAYMENT BOND
Bond No. 58655214
KNOW ALL MEN BY THESE PRESENTS: that
West Construction, Inc.
(Name of CONTRACTOR)
318 Sou Dixie Highway Suite 4 -5 Lake Worth, Flori 3 2751
(Address of CONTRACTOR)
Florida , hereinafter called
(Corporation, Partnership or Individual)
Principal and Western Surety Company
(Name of Surety)
2405 Lucien Way, Maitland, Florida 32751
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto 1) City. of Sanford, FL
hereinafter called OWNE 7 full and j ust Sum of Four Million Four Hundred Four Thousand
F ive Hundr One ag)k& - 4,404,50 � in lawful money of the
United States, for the payment of which sum well and truly. to be made, we bind ourselves,
successors, and assigns, Jointly and severally, firmly by these presents. The sum shall not be
less than one hundred ten percent (110 %) of the Contract Price.
THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a
certain Agreement with the OWNER, dated the —. day of _ _ _
a copy of which is hereto attached and made a part hereof for the construction of 2)
Fort Mellon Park Re construction Project, Phase 1
9) Name of Owner
2) Name of Project Identified in Instructlons to Bidders
The Surety shall be bound by any and all alternative dispute resolution awards and settlements
to the same extent as CONTRACTOR is bound.
NOW, THEREFORE, the condition of this obligation is such that if Principal shall promptly make
payments to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal
with labor, Materials, or supplies, used directly or indirectly by Principal in the prosecution of the
Work provided for in the Agreement, then this obligation shall be void; otherwise, It shall remain
In full force and effect subject, however, to the following conditions:
1. This Bond is furnished for the purpose of complying with the requirements of
Section. 255,05, Florida Statutes, as the same may be amended.
2. Therefore, a claimant, except a laborer, who is not in privity with the
CONTRACTOR and who has not received payment for his labor, Materials or
00610.1
supplies shall, within forty -five (45) days after beginning to furnish labor,
Materials or supplies for the prosecution of the Work, furnish the CONTRACTOR
with a notice that he intends to look to the Bond for protection, A claimant who is
not in privity with the CONTRACTOR and who has not received payment for his
labor, Materials or supplies shall within ninety (90) days after performance of the
labor or completion of delivery of the Materials or supplies, or, with respect to
rental equipment, within 90 days after the date that the rental equipment was last
on the job site available for use, deliver to the CONTRACTOR and to the Surety
written notice of the performance of the labor or delivery of the Materials or
supplies and of the nonpayment. No action for the labor, Materials or supplies
may be instituted against the CONTRACTOR or the Surety on the bond after one
(1) year from the performance of the labor or completion of the delivery of the
Materials or supplies.
3, The Surety, for value received, hereby stipulates and agrees that its obligations
hereunder shall remain in full force and effect notwithstanding (1) amendments or
modifications to the Agreement entered into by OWNER and Principal without the
Surety's knowledge or consent, (11) waivers of compliance with or any default
under the Agreement granted by OWNER to Principal without the Surety's
knowledge or consent, or (iii) the discharge of Principal from its obligations under
the Agreement as a result of any proceeding initiated under The Bankruptcy
Code of 1978, as the same may be amended, or any similar state or federal law,
or any limitation of the liability or Principal or its estate as a result of any such
proceeding.
4. Any changes In or under the Agreement or Contract Documents and compliance
or noncompliance with any formalities connected with the Agreement or the
changes therein shall not affect Surety's obligations under this Bond and Surety
hereby waives notice of any such changes. Further, Principal and Surety
acknowledge that the Sum of this Bond shall increase or decrease in accordance
with the Change Orders (unilateral. and bilateral) or other modifications to the
Agreement or Contract Documents.
5, The Performance Bond and the Payment Bond and the covered amounts of each
are separate and distinct from each other.
IN WITNESS WHEREOF, this instrument is executed this the day of
Segretary (Principal)
Matthew F. West, Secretary
Typed Name
West Construction, Inc.
A Pr1incl,l (Contra Qr)
By (Signature)
Martha A. Morgan, President
Typed Name and Title
(CORPORATE SEAL)
318 South Dixie Highway, Su ite 4 -5
Address
00610 -2
a
(Witness to Principal)
Typed Name
ATTEST;
as per attached power of at torney
(Surety) Secretary
Typed Name
IM, E AL
Wi ne s s to Surety
Olga Rodriguez
1 Typed Name f
y Witness as to Surety
Melinda Rosenhaus
Typed Name
Lake Worth, Florida 33460
City, State, Zip
561/588 -2027 561/588 -9419
Telephone No. Facsimile No.
Western Surety Company
Surety
877- 276 -7511 605/330 -7416
Telephone .No. Facsimile No.
Attorney -in -Fact
D. Michael Stevens
Typed Name
2405 Lu Way
Address
Maitland, FL 32751
City, State, Zip
877/276 -7 605/330 -7416
Telephone No. Facsimile No.
NOTE: Date of the Bond must not be prior to date of Agreement. If CONTRACTOR is a joint
venture, all venturers shall execute the Bond. If CONTRACTOR Is Partnership, all partners
shall execute Bond.
IMPORTANT: Surety companies executing Bonds must appear on the Treasury Department's
most current list (Circular 570 as arnended) and be authorized to transact business in the State
of Florida, unless otherwise specifically approved in writing by OWNER.
ATTACH a certified Power -of- Attorney appointing individual Attorney -in=Fact for execution of
Performance Bond on behalf of Surety.
END OF SECTION
00610 -3
Western Surety Company
POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN-FACT
Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation
having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby
make, constitute and appoint
Don A Lambert Jr, D Michael Stevens, individually
of Palm Beach Gardens, FL, its true and lawful Attorney(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for
and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts •- for any and all surety
bonds and any and all consents required by the State Department of Transportation of the State of Florida, incident to the release of retained
percentages and /or estimates on engineering and /or construction contracts - and to bind it thereby as fully and to the same extent as if such
instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby
given, are hereby ratified and confirmed.
This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by
the shareholders of the corporation.
In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corporate seal to
be hereto affixed on this 24th day of October, 2006.
rs�Tr�s WESTERN SURETY COMPANY
'9T i^jn
o�,,,,TM
Paul . Brutlat, Senior Vice President
State of South Dakota 1
County of Minnehaha J } ss
On this 24th day of October, 2006, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that
he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and
which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was
so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and
acknowledges same to be the act and deed of said corporation.
My commission expires fsss .. ,, 5 , , i5 , tistiS � stiss {
f D. KRELL i
NOvember30, 2012 r NOTARY PUBLIC i
X
SOUTH TH DAKOTA SEAL J
r
r r
fti555554 ss55tisStitiSSS55 55 +
CERTIFICATE D. KrW�. ry pub lic
I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in
force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed
my name and affixed the seal of the said corporation this day of
w,, -
;Q?e 1 - WESTERN SURETY COMPANY
fstSEAV : *Y�
DA
.1 ,�-