HomeMy WebLinkAbout4355 ST JOHNS PARKWAY 18-4355CITY OF SANFORD
0 0 T 2 5 2018 BUILDING & FIRE PREVENTION
PERMIT APPLICATION
Application No:
Documented Construction Value: $
1<S -43s5-
24470.00
4355 ST JOHNS PKWY SANFORD, FL 32771 Historic District: Yes ❑ No ❑X
Parcel ID: 28-19-30-5JB-0000-034A ❑ Commercial
Type of Work: New ❑ Addition ❑ Alteration ❑ Repair x❑ Demo ❑ Change of Use ❑ Move ❑
Description of Work: Roof Coating on Commercial Building -FL i � --p3.4 — 94
Plan Review Contact Person:
Phone: 321-363-3871
Rebecca Smith Title: Owner
Fax:
Email: info@xlr8roofing.com
Property Owner Information
Name MOLEE REALTY SOUTH LLC/ Anthony Molee
Phone:
Street: 4355 ST JOHNS PKWY
City, State Zip:
SANFORD, FL 32771
Name XLR8 Roofing
Street: 485 Specialty Pt
City, State Zip: Sanford, FL 32771
Name:
Street:
City, St, Zip:
Bonding Company:
Address:
407-328-0771
Resident of property?: Owner of Commercial
Business
Contractor Information
Phone: 321-363-3871
Fax:
State License No.: CCC1331278
Architect/Engineer Information
Phone:
Fax:
E-mail:
Mortgage Lender:
Address:
WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR
PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE
RECORDED AND POSTED ON THE JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN
FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE RECORDING YOUR NOTICE OF
COMMENCEMENT.
Application is hereby made to obtain a permit to do the work and installations as indicated. I certify that no work or installation has
commenced prior to the issuance of a permit and that all work will be performed to meet standards of all laws regulating construction
in this jurisdiction. I understand that a separate permit must be secured for electrical work, plumbing, signs, wells, pools,
furnaces, boilers, heaters, tanks, and air conditioners, etc.
FBC 105.3 Shall be inscribed with the date of application and the code in effect as of that date: 5'h Edition (2014) Florida Building Code
Revised: June 30, 2015 Permit Application
NOTICE: In addition to the requirements of this permit, there may be additional restrictions applicable to this property that may be
found in the public records of this county, and there may be additional permits required from other governmental entities such as water
management districts, state agencies, or federal agencies.
Acceptance of permit is verification that I will notify the owner of the property of the requirements of Florida Lien Law, FS 713.
The City of Sanford requires payment of a plan review fee at the time of permit submittal. A copy of the executed contract is required
in order to calculate a plan review charge and will be considered the estimated construction value of the job at the time of submittal.
The actual construction value will be figured based on the current ICC Valuation Table in effect at the time the permit is issued, in
accordance with local ordinance. Should calculated charges figured off the executed contract exceed the actual construction value,
credit will be applied to your permit fees when the permit is issued.
OWNER'S AFFIDAVIT: I certify that all of the foregoing information is accurate and that all work will
be done in compliance with all applicable laws regulating construction and zoning.
Signature of Owner/Agent Date
Print Owner/Agent's Name
Signature of Notary -State of Florida Date
Owner/Agent is Personally Known to Me or
Produced ID Type of ID
Signature of Contractor/Agent Dale
Print Contractor/Agent's
BELOW IS FOR OFFICE USE ONLY
Permits Required: Building ❑ Electrical ❑ Mechanical ❑ Plumbing❑ Gas[] Roof ❑
Construction Type: Occupancy Use:
Total Sq Ft of Bldg:
Min. Occupancy Load:
New Construction: Electric - # of Amps
Fire Sprinkler Permit: Yes ❑ No ❑
APPROVALS: ZONING:
ENGINEERING:
COMMENTS:
# of Heads
UTILITIES:
Flood Zone:
# of Stories:
Plumbing - # of Fixtures
Fire Alarm Permit: Yes ❑ No ❑
WASTE WATER:
FIRE: BUILDING: a
Revised: June 30, 2015 Permit Application
:p 'W"', RESECCASMITH
�i
MY COMMISSION#FF 969994
raF
EXPIRES: March 10, 2020
`Bonded Thru Notary Public Und"riters
Contractor/Agent
is _ Personally Known to Me or
Produced ID
Type of ID
BELOW IS FOR OFFICE USE ONLY
Permits Required: Building ❑ Electrical ❑ Mechanical ❑ Plumbing❑ Gas[] Roof ❑
Construction Type: Occupancy Use:
Total Sq Ft of Bldg:
Min. Occupancy Load:
New Construction: Electric - # of Amps
Fire Sprinkler Permit: Yes ❑ No ❑
APPROVALS: ZONING:
ENGINEERING:
COMMENTS:
# of Heads
UTILITIES:
Flood Zone:
# of Stories:
Plumbing - # of Fixtures
Fire Alarm Permit: Yes ❑ No ❑
WASTE WATER:
FIRE: BUILDING: a
Revised: June 30, 2015 Permit Application
i
��T(-Gxalyttct_v�Y�a. _..._. s.R�.^su�_..t• .i_•_ ,
r
f
I
i
��T(-Gxalyttct_v�Y�a. _..._. s.R�.^su�_..t• .i_•_ ,
- •- ._ .._ ;.,_.. _.. _. __. .. )^)1 .raid-'- 1.1'>��
• General Contractor/ Roofing Contractor
e'oh►srRucnpN • Servicing Seminole, Orange, Volusla, Flagler & XLR8 Roofing & Construction, LLC
Brevard counties 400 Specialty Pt,
Sanford, Fl. 32771
321.363.3871
Owner's Name: owner's Address:
xlr8roofEng.com
2 , > Ui.err FL Lic. No. CCC1331278 / CRC1331831
Owner's City, State, Zip: Owner's Phone: Owner's Alt. Phone: info@xlr8roofing.com
Project Name & Address: Email:
Project
3,G 1q- Jowls Rc.w AAV _J F1, I
/WE, the Owner(s) of the premises described above authorize the Above named hereinafter referred to as "Contractor", to furnish all materials and labor
necessary to roof and/or improve these premises according to the following terms, specifications and provisions:
a. Description of the work and the materials to be used:
■ r h,,.,p -- _.. - -
•tZG
--
�i�•w - _.. --. ...
Pull all permits __..
■ p pass all inspections required by Florida Building ode
Clean up entire property to ensure no nails or roofing debris Is left
■ Rotted wood replacement Is all unforseen and photo dace -m nt tion will be taken and Is billed after the fact as follows
Rotted plywood replacement is per sheet at $65.00
• Rotted lx or 2x is per liner foot at $SSO -
ea_�".__
• iA1tr� I�'.�Sw-/c-(ter-_�►i.L1._�4►f._?!.� 7 —
We offer aNyear workmanship warranty. The manufacturer warranty Is-A"years 100% labor and materials y/,i Cyt � k - w6k f IrA0
Acts of God are not covered under the warranty (storm damage, hall, wind, fire, trees) — — -4i
-
__ °. ;•�-tnG�v _eS ..S .11 t/v,�-�•l__ —p�! t%.r - —..._.
g C�i,v1C•
b. Description of any areas that will NOT be worked on:
THIS LIST OF SPECIFICATIONS MAY BE CONTINUED ON SUBSEQUENT PAGES (SEE PAGE NUMBER BELOW) -
c. Payment: Contractor proposes to perform the above work, (subject to any additions and/or deductions niersu • •* to authorized change orders), for the
Total Sum of$,� U iv Down Payment (if any) $ i 2,13`�
PAYMENT DUE WHEN AMOUNT PAYMENTS TO BE MADE IN INSTALLMENTS AS FOLLOWS:
1, Contract is signed, before work Is started $
2• Work iscomDleted S'1Z f��."�
3.
4.
d. Commencement and Completion of Work: Substantial commencement of work shall mean either the physical delivery of materials onto the premises
or the performance of any labor and shall be subject to any permissible delays as per provision (5) on the reverse side.
Approximate Start Date: 3-5 weeks from acceptance
e. Acceptance: This contract is approved and accepted. I (we) understand there are no oral agreements or understandings between the parties of this
agreement. The written terms, provisions, plans (if any) and specifications In this contract is the entire agreement between the parties. Changes In this
agreement shall be done by written change order only and with the express approval of both parties. Changes may Incur additional charges.
Additional Provisions Of This Contract Are On The Reverse Side And May Be Continued On Subsequent Pages (see page number below). Read
"Arbitration of Disputes" rovision on page two (2), provision 13 and the NOTICE following this provision. If you agree to arbitration, Initial on the line
below the NOTICE w e indicated. Also, initial In the same place on EACH COPY of this contract.
7:5Cy You, the Buyer, may cancel this transaction at any time prior
approved acc ted (owner) wwdate to midni ht f *9. *16: d b ' d
a)gproved and ac pte (o r)
/
approved (contractor)
date
g o e tr ustness ay after the date of this
transaction. See the attached Notice of Cancellation form for
an explanation of this right.
N TE• This contract may be withdrawn after 30 days from
�74—t I' if not approved and signed by BOTH parties.
Page ONE of 2 Total Pages
ADDITIONAL PROVISIONS- Unless otherwise specified herein, the following additional provisions are expressly incorporated into this contract:
1. Contract, Plans, Specifications, Permits and Fees. The work described in '
this contract shall be done according to the plans and the plan specifica-
tions (if any) except in the case of conflict when the provisions of this
contract shall have control over both the plans and the plan specifications.
All required building permits will be paid for by owner and obtained by
Contractor. All other charges, taxes, assessments, fees etc., of any kind
whatsoever, required by any government body, telephone or utility compa-
ny or the like shall be paid for by Owner.
2.Installation. Contractor has the right to subcontract any part of, or all of,
the work herein
3.Change Orders. Should Owner, construction lender, or any government
body or inspector require any modification to the work covered under this
contract, any cost incurred by Contractor shall be added to the contract
price as extra work and Owner agrees to pay Contractor his normal selling
price for such extra work. All extra work as well as any other modifications
to the original contract shall be specified and approved by both parties in a
written change order. All change orders shall became a part of this contract
and shall be Incorporated herein.
4.Owners Responsibility: Insurance etc. Owner is responsible for the fol-
lowing: (1) to see that all necessary water, electrical power, access to
premises, and toilet facilities are provided on the premises. (2) to provide a
storage area on the premises for equipment and materials. (3) to relocate
and protect any item that prevents Contractor from having free access to
the work areas such as but not limited to TV or radio antennas, vehicles,
tools or garden equipment. In the event that Owner falls to relocate such
items, Contractor may relocate these items as required but in no way is
Contractor responsible for damage to these items during their relocation
and during the performance of the work. (4) to obtain permission from the
owner(s) of adjacent property(les) that Contractor must use to gain access
to the work areas. Owner agrees to be responsible and to hold Contractor
harmless and accept any risks resulting from the use of adjacent
property(ies) by Contractor. (5) to correct any existing defects which are
recognized during the course of the work. Contractor shall have no liability
for correcting any existing defects such as, but' not limited to, dry rot,
structural defects, or code violations. (6) to maintain property insurance
with Fire, Course of Construction, all Physical Loss with Vandalism and
Malicious Mischief clauses attached, In a sum at least equal to the contract
price, prior to and during performance of this contract. If the project Is
destroyed or damaged by an accident, disaster or calamity, or by theft or
vandalism, any work or materials supplied by Contractor In reroofing or
restoring the project shall be paid for by Owner as extra work.
S.Delay. Contractor shall not be held responsible for any damage occa-
sioned by delays resulting from: work done by Owners subcontractors,
extra work, acts of owner or owners agent Including failure of owner to
make timelyrogress payments or payments for extra work, shortages of
material and/or labor, bad weather, fire, strike, war, governmental regula-
tions, or any, other contingencies unforeseen by Contractor or beyond
Contractor's reasonable control.
6.Surplus Materials and Salvage. Any surplus materials left over after this
contract has been completed are the property of Contractor and will be
removed by same. No credit is due Owner on, returns for any surplus
materials because this contract is based upon a complete job. All salvage
resulting from work under this contract Is the property of Contractor.
7.Cleanupp & Advertising. Upon completion, and after removing all debris
and surplus materials, wherever possible, Contractor will leave premises In
a neat, broom clean condition. Any debris consisting of dust, dirt, asphalt,
or small bits of materials that settle into attics, garage areas, or any other
area being worked over with open beam ceilings or no attic, is unavoidable
and Contractor shall not be responsible for this cleanup. Contractor recom-
mends that Owner lay out drop cloths to protect such areas wherever
owner discovers debris infiltration. Owner hereby grants to Contractor the
right to display signs and advertise at the job site for the period of time
starting at the date of signing of this contract and 'continuing uninterrupted
until fourteen (14) days past the date the job is completed and payment in
full has been made. Owner grants Contractor the right to take "before" and
"after" photos and to publish the project street address on a "references"
list which may be given to prospective customers.
8.Concealed Damage & Dry Rot. Contractor will inform Owner of any dry
rot or other sub -roof deterioration which is concealed and is discovered
during the course of the work. Contractor is not responsible to repair any
such discovered deterioration and any work done by Contractor to remedy
such discovered deterioration will only be done as extra work In a written
change order.
9.Termites, Pests & Hazardous Substances. Owner understands that Con-
tractor is not qualified or licensed as an Inspector or abatement contractor
for Hazardous Materialsas defined by the government), or for Pests (in-
cluding Termites). Should any such hazardous substances or Pest be sus-
pected to be present on the premises, it is the Owners' responsibility to
arrange and pay for inspection and abatement. Contractor cannot certify or
warrant your building as being free of hazardous substances or paste.
10.R'
0. Right to Stop Work and to Withhold Payment on labor and Materials.
If any payment is not made to Contractor as perthis contract, Contractor
shall have the right to stop work and keep the job idle until all past due
progress payments are received. Contractor is further excused by Owner
from paying any material, equipment and/or labor suppliers or any subcon-
tractors (hereinafter collectively called "suppliers"), during the period that
Owner is in arrears in making payments to Contractor for bills received
during that same period. if these same "suppliers" make demand upon
Owner for payment, Owner may make such payment on behalf of Contrac-
tor and Contractor shall reimburse Owner for this amount at such time that
Owner becomes current with Contractor for all past due payments. Owner
is responsible to verify the true amounts owed by Contractor to these same
"suppliers", prior to making payment on behalf of Contractor. Owner shall
not be entitled, under any circumstances, to collect as reimbursement from
Contractor any amount greater than that exact amount actually and truly
owed by Contractor to these same "suppliers", for work done or materials
supplied on Owner's job.
11. Collection. Owner agrees to pay all collection fees and charges including
but not limited to all legal and attorney fees that result should Owner
default inpayment of this contract. Overdue accounts are subject to inter-
est charged at the rate of 18% per annum or at the highest rate allowed by
law.
12. Legal Fees. In the event litigation or arbitration arises out of this con-
tract, prevailing party(les) are entitled to all legal, arbitration, and attorney
fees. The court or arbitrator shall not be bound to award fees based on any
set, fee schedule but shall if it so chooses, award the true amount of all
costs, expenses and attorney fees paid or incurred.
13. Arbitration of Disputes. Any controversy or claim arising out of
or relating to this proposal/contract, or the breach thereof, shall
be settled by arbitration in accordance with the applicable Con-
struction Industry Arbitration Rules of the American Arbitration
Association which are In effect at the time the demand for arbitra-
tion is filed. A judgment upon the award rendered by the
arbitrator(s) may be entered In any court having jurisdiction there-
of. Any arbitration award shall be subject to correction and/or
vacation for the reasons stated in the law. The arbitrator shall
award reasonable attorneys fees and expenses to the prevailing
party. After being given due notice, should any party fail to appear
at or participate in the arbitration proceedings, the arbitrator shall
make an award based upon the evidence presented by the
party(les) who do (does) appear and participate. Notwithstanding
Contractor's right to arbitrate, Contractor does not waive any of its
lien rights. Venue for arbitration hearings shall be the project
county unless otherwise agreed to by the parties.
NOTICE: By initialing in the space below you are agreeing to have
any dispute arising out of the matters included in the "arbitration
of disputes" provision decided by neutral arbitration as provided
by law and you are giving up any rights you might possess to have
the dispute litigated in a court or jury trial. By initialing in the space
below you are giving up your judicial rights to discovery and ap-
peal, unless those rights are specifically, included In the "arbitra-
tion of disputes" provision. If you refuse to submit to arbitration
after agreeing to this provision, you may be compelled to arbitrate
under the authority of the applicable laws. Your agreement to this
arbitration provision is voluntary.
We have read and understand the foregoing and agree to submit
disputes arising out of the tters included in the "arbitration of
disputes" provision to ne ral arbitration.
I Agree to Arbitration: -
initials of Owner) (Initials of Owner)
FLORIDA HOMEOWNER'S CONSTRUCTION RECOVERY FUND
PAYMENT MAY BE AVAILABLE FROM THE FLORIDA HOMEOWNER'S
CONSTRUCTION RECOVERY FUND IF YOU LOSE MONEY ON A PROJECT
PERFORMED UNDER CONTRACT, WHERE THE LOSS RESULTS FROM
SPECIFIED VIOLATIONS OF FLORIDA LAW BYA LICENSED CONTRACTOR.
FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A
CLAIM, CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING
BOARD AT THE FOLLOWING TELEPHONE NUMBER AND ADDRESS:
PHONE: (850) 487-1395
CONSTRUCTION INDUSTRY LICENSING BOARD
CONSTRUCTION INDUSTRY RECOVERY FUND
2601 BLAIR STONE ROAD
TALLAHASSEE, FLORIDA 32399-0783
"ANY CLAIMS FOR CONSTRUCTION DEFECTS ARE SUBJECT TO
THE NOTICE AND CURE PROVISIONS OF CHAPTER SS8, FLORIDA
STATUTES."
Page TWO of _2_ Total Pages
LIMITED POWER OF ATTORNEY
Altamonte Springs, Casselberry, Lake Mary, Longwood, Sanford,
Seminole County, Winter Springs
Date: l o I as ) IS,
I hereby name and appoint: Paula Rodriguez / Whitney Brown
an agent of: XLR8 Roofing & Construction LLC
to be my lawful attorney-in-fact to act for me to apply for, receipt for, sign for and do all things
necessary to this appointment for (check only one option):
IX The specific permit and application for work located at:
4355 ST JOHNS PKWY SANFORD, FL 32771
(Street Address)
Expiration Date for This Limited Power of Attorney: 12/31/18
License Holder Name: David Hambley
State License Number:
CCC 1331278
Signature of License Holder:
STATE OF FLORIDA
COUNTY OF _5F.L{ " L 7 �J
The foregoing instrument was acknowledged before me this,;9 day of axzm
2012L_, by D OV 1 i7 4 -Ir' M P)j Fry who is "ersonally known
to me or o who has produced
identification and who did (did not) take an oath.
Signature
(Notary Seal) RLbuf i} '45d rT}}
Print or type name
REBECCA SMITH
MY COMMISSION II'p �299B94 Notary Public -St�at�er -o�f,�
E%pIRES'.Marek 0 Commission No. i'tr' 1
e •ge„dedThruN0tA1 liaBnderv/d�' My Commission Expires: O—
(Rev. 08.12)
Grant
Court & Comptroller Seminole County, FL
Ie:1982; (1 PAGES) RCD: 10/18/2018 2:44:47 PM
Prepared By Whitney Blown
400 Specialty Pt
PermitNo Sanford FI 32771
Tell Parcel Number
28-19-30SJ13-0000-034A NOTICE OF COMMENCEMENT
Slate of Florida
The UNDERSIGNED hereby gives notice that inprovemenl will be made to certain real
property, and in accordance with Chapter 713, Florida Statutes, the following Information
Is provided in this Notice of Commencement
1. Description of Property: (Legal description of the property, and street address if applicable.)
W 112 OF LOT 34 SANFORD CENTRAL PARK PB 33 PG 64 TO 66
2. General description of improvement
RE -ROOF
3. Owner Information (or Lessee Information If the Lessen contracted for the Improvement):
a. Name: MOLEE REALTY SOUTH LLC / ANTHONY MOLEE
Address: 4355 ST JOHNS PKWY SANFORD, FL 32771
b. interest in property:
c Name and address of fee simple titleholder Of other than owner):
4. Contractor Information:
a. Name: XLR8 Racing d Consbudion, LLC
Address: 400 Specialty PcinL Sanford, FL 32771
b. Contractors phone number. 321-363.3871
5. Surety Of applicable, a copy of the payment bond 5 attached):
a. Name:
Address:
b. Phone number:
c. Amount of bond: $ .0D
6. Lender Information:
a. Name:
Address:
b. Lenders phone number.
7. Persons within the State of Florida designated by Owner upon whom nrotices or other documents may be
served as prodded by Section 713.13(1)(e)% Florida Stature:
a. Name:
Address:
CERTIFIEDCOPY GRANTMALOY
CLERK RCUiTCOURT e: �`
AND COIV, TR LER
t r•
1T, FLORIDA
Q. `Y V
SENdNOIE
BY TY CLERK
Date
FOR CLERK'S OFFICE USE ONLY
b. Phone numbers of designated persons:
8. In addition to hbnsalt Owner designates,
a. Name: of to receive a copy
of the Lienors Notice as provided in Section 713.13(1)(b), Florida Statutes.
b. Phone number
9. Expiration dale of Notice of Commencement (Nem7cafon dab is 7 year born Ne dab ofnerndrg unless a dEforadda isspecifleft.
WARNING TO OWNER: ANY PAYMENTS MADE BY THE OWNER AFTER THE EXPIRATION OF THE NOTICE OF COMMENCEMENT ARE CONSIDERED
IMPROPER PAYMENTS UNDER CHAPTER 713, PART I, SECTION 713.13, FLORIDA STATUTES, AND CAN RESULT IN YOUR PAYING TWICE FOR
IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE JOB SITE BEFORE THE FIRST
INSPECTION. IF YOU INTEND TO OBTAIN FINANCING, CONSUL YOUR LENDER OR AN ATTORNEY BEFORE COMMENCING WORK OR RECORDING
YOUR NOTICE OF COMMENCEMENT. /
SlgnaloysTibef0ffice
State of , k M, County of
The forgoing instrument was acknowledged beloeme this day of 20 by
(TYpeofauawdty... e.g. o9xer, suers. aalbney In fact)
� /
Sgnatura of Notary Pu is—Slate ofFlloride
Personally Known _ OR --Z Produced ID
iq0ftcc Notary Public State of Florida
Paulo J Rodriguez
+� 3� My Commission GG 199671
yq yde expires 03252022
PdnL Type ars p emeo Notary u c
r
Type of to Produced NJ SVM I4ilkl�b
MQ 135 �53i� aql� Iti
9/25/2018 Detail by Entity Name
DIVISION OF CORPORATIONS
rgr� r( r1 fir . i
an (4 if ifiI.Y1111f, vf Florida we/Wir
Department of State 1 Division of Corporations / Search Records / Detail By Document Number 1
Detail by Entity Name
Florida Limited Liability Company
MOLEE REALTY SOUTH,
LLC
EjUng Information
2017
Document Number
L08000000959
FEI/EIN Number
42-1752112
Date Filed
01/03/2008
Effective Date
01/03/2008
State
FL
Status
ACTIVE
Principal Address
4355 ST. JOHN'S PARKWAY
SANFORD, FL 32771
fling ss
4355 ST. JOHN'S PARKWAY
SANFORD, FL 32771
&gistered Agent Name & Address
MOLEE, ANTHONY
4355 ST. JOHN'S PARKWAY
SANFORD, FL 32771
Authorized Person(e) Detail
Name & Address
Title MGRM
MOLEE, ANTHONY
4355 ST. JOHN'S PARKWAY
SANFORD, FL 32771
Annual Reports
Report Year
Filed Date
2016
02/20/2016
2017
01/09/2017
2018
01/12/2018
Document Images
I01/1212018 --ANNUAL REPORT View image in PDF format I I
http://search.sunbiz.org/inquiry/CorporationSearch/SearchResultDetail?inquirytype=EntityName&directionType=Initial&searchNameOrder=MOLEERE... 112
9/25/2018
petail by Entity Name
01/0912017 — ANNUAL
REPORT
View image in PDF format J
02/20/2016 -- ANNUAL
REPORT
View image in PDF format
01/2812015 -- ANNUAL
REPORT
View image in PDF format
01/09/2014 -- ANNUAL REPORT
View image in PDF format I
01/24/2013 — ANNUAL
REPORT
View image in PDF format
041180012 -- ANNUAL
REPORT
View image in PDF format
02/01/2011 —ANNUAL
REPORT
View image in PDF format
02/16/2010 -- ANNUAL
REPORT
View image in PDF format
02/0312009 -- ANNUAL
REPORT
View image in PDF format
01/03/2008 -- Florida Limited Liability,
View image in PDF format
flotu7.t Ueltai file fit pit Sthtt DIV[ stoll of (CotJ uIatlotts
.. 212
GREEK
TECHNICAL SERVICES, LLC
Certificate of Authorization No. 29824
17520 Edinburgh Drive
Tampa, FL 33647
(813)480-3421
EVALUATION REPORT FLORIDA BUILDING CODE, 6r" EDITION (2017)
Manufacturer: GACO WESTERN, LLC
Specification
Issued April 19, 2018
200 West Mercer Street, Suite 202
ASTM D 6083
Acrylicquick-set elastomeric coating that is brush, roller orspray-applied.
Seattle, WA 98119
ASTM D 6694
Silicone elastomeric coating that is brush, roller orspray-applied.
(800)331-0196
ASTM D 6694
Silicone solvent -free, single -component, moisture -cured, waterproof
elastomeric coating that is brush, roller orspray-applied.
www.paco.com
ASTM D 6694
Silicone solvent -free, single -component, moisture -cured, waterproof
elastomeric coating that is brush, roller orspray-applied.
Manufacturing Plants: Waukesha, WI
PERMIT #
1 Silicone elastomeric coating that is brush, roller orspray-applied.
Quality Assurance: UL LLC (QUA1743)
SCOPE
Category: Roofing
Subcategory: Cements -Adhesives-Coatings
Code Sections: 1507.14.3,1507.15.2
�'
CE
Properties: Physical Properties
REFERENCES
Entity Report No.
Standard
Year
PRI Construction Materials Technologies (TST5878) GWI-024-02-02
ASTM D 6694
2008
PRI Construction Materials Technologies (TST5878) GWI-026-02-01
ASTM D 6694
2008
PRI Construction Materials Technologies (TST5878) GWI-042-02-01
ASTM D 6694
2008
PRI Construction Materials Technologies (TST5878) GWI-043-02-01
ASTM D 6694
2008
PRI Construction Materials Technologies (TST5878) GWI-044.02-01
ASTM D 6694
2008
PRI Construction Materials Technologies (TST5878) GWI-045-02-01
ASTM D 6083
2005e01
PRODUCT DESCRIPTION
Products
Specification
Description
GacoFlex A-31
ASTM D 6083
Acrylicquick-set elastomeric coating that is brush, roller orspray-applied.
GacoFlex S-10
ASTM D 6694
Silicone elastomeric coating that is brush, roller orspray-applied.
GacoFlex S-20
ASTM D 6694
Silicone solvent -free, single -component, moisture -cured, waterproof
elastomeric coating that is brush, roller orspray-applied.
GacoFlex 5-21
ASTM D 6694
Silicone solvent -free, single -component, moisture -cured, waterproof
elastomeric coating that is brush, roller orspray-applied.
GacoRoof GR -16
I ASTM D 6694
1 Silicone elastomeric coating that is brush, roller orspray-applied.
GW18002 FL14724-R4 Page 1 of 6
This evaluation report is provided for State of Florida product approval under Rule 61G20-3. The manufacturer shall notify CREEK
Technical Services, LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, Installation, recommended use, or other product attributes that are not
specifically addressed herein.
CREEK
TECHNICAL SERVICES, LLC
APPLICATION
The following nates shall be observed when using the application tables below:
1. All surfaces shall be repaired, clean, dry,and fre a of debris prior to application.
2. Roof coating may be spray, brush or roller applie�.
3. Applications are valid for new and existing roof systems.
GACO WESTERN, LLC
GacoFlex Roof Coatings
Application of GacoFlex A-31
Substrate
New or Existin Minimum Application Rate
Spray Polyurethane Foam Roofs Gacol z i A-31 applied in three (3) coats (base, intermediate and top) at
a minimum rate of 1.25 gal/100 ft' per coat
Application o. GacoFlex S-10
Substrate
New or Existing)
Minimum Application Rate
Primed with GacoFlex E-5320 Primer at a rate of 0.3 ga11100 ft2
followed by one of the following:
Acrylic Coatings
-One coat of GacoFlex S-10 applied at a minimum rate of 2.2 gal/100ft2
-Two (2) coats (base and lop) of GacoFlex S-10 applied at a minimum
rate of 1.1 ga11100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.4 gal/1 00 ft'
followed by one of the following:
BUR Membranes - Smooth -surfaced
-One coat of GacoFlex 5-10 applied at a minimum rate of 2.2 ga11100112
-Two (2) coats (base and top) of GacoFlex S-10 applied at a minimum
rate of 1.1 gall100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/100 ft'
followed by one of the following:
Galvanized Steel Metal Panels
-One coat of GacoFlex S-10 applied at a minimum rate of 2.2 gavl00ft2
-Two (2) coats (base and top) of GacoFlex S-10 applied at a minimum
rate of 1.1 gal/100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 ga11100 ft2
followed by one of the following:
KEE Single -Ply Membrane
-One coat of GacoFlex S-10 applied at a minimum rate of 2.2 gaIl100ft
-Two (2) coats (base and top) of GacoFlex 5-10 applied at a minimum
rale of 1.1 gal/100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/1 00 112
followed by one of the following:
PVC Single -Ply Membranes
-One coat of GacoFlex 5-10 applied at a minimum rate of 2.2 ga111001112
-Two (2) coats (base and top) of GacoFlex 5-10 applied at a minimum
rate of 1.1 ga11100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/100 ft2
followed by one of the following:
SBS Modified Bitumen Membranes - Granule -surfaced
-One coat of GacoFlex 5-10 applied at a minimum rate of 2.2 ga11100ft
-Two (2) coats (base and top) of GacoFlex 5-10 applied at a minimum
rate of 1.1 gal/100(12 per coat
Applied according to one of the following:
Spray Polyurethane Foam Roofs
-One coat of GacoFlex S-10 applied at a minimum rate of 2.2 ga11100ft
-Two (2) coats (base and top) of GacoFlex 5-10 applied at a minimum
rate of 1.1 gal/100112 per coat
2 of
This evaluation report is provided for State of Florida product approval under Rule 61G20-3. The manufacturer shall notify CREEK
Technical Services, LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, installation, recommended use, or other product attributes that are not
specifically addressed herein.
GREEK
TECHNICAL SERVICES, LLC
GACO WESTERN, LLC
GacoFlex Roof Coatings
Application of GacoFlex S-20
Substrate
New or Existing)
Minimum Application Rate
Primed with GacoFlex E-5320 Primer at a rale of 0.3 gal/100 ft'
followed by one of the following:
Acrylic Coatings
-One coat of GacoFlex S-20 applied at a minimum rate of 1.5 gaV100ft2
-Two (2) scats (base and top) of GacoFlex S-20 applied at a minimum
rate of 0.75 gaYl00ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/1 00 ft2
followed by one of the following:
APP Modified Bitumen Membranes - Granule -surfaced
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 ga11100ft2
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 ga11100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 ga11100 1112
followed by one of the following:
APP Modified Bitumen Membranes - Smooth -surfaced
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 ga11100ft2
-Two (2) coats (base and top) of GacoFlex S-20 applied at a minimum
rate of 0.75 gal/100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.4 gaV100 ft'
followed by one of the following:
BUR Membranes - Smooth -surfaced
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 gal/100ft'
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 gaV100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/1 00 ft2
followed by one of the following:
EPDM Single -Ply Membranes
-One coat of GacoFlex S-20 applied at a minimum rate of 1.5 gall100112
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 gal/100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/100 ft'
followed by one of the following:
Galvanized Steel Metal Panels
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 ga11100112
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rete of 0.75 gaV100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 ga1I10011'
followed by one of the following:
KEE Single -Ply Membrane
-One coat of GacoFlex S-20 applied at a minimum rate of 1.5 ga11100112
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 gal/100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/100 112
followed by one of the following:
PVC Single -Ply Membranes
-One coat of GacoFlex S-20 applied at a minimum rate of 1.5 ga11100ft2
-Two (2) coats (base and top) of GacoFlex S-20 applied at a minimum
rate of 0.75 ga11100112 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 ga11100 ft'
followed by one of the following:
SBS Modified Bitumen Membranes - Granule -surfaced
-One coat of GacoFlex S-20 applied at a minimum rale of 1.5 ga11100ft2
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rale of 0.75 gall100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/1 00 ft2
followed by one of the following:
SBS Modified Bitumen Membranes - Smooth -surfaced
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 gal/1001912
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 gat/1001t2 per coat
Applied according to one of the following:
Spray Polyurethane Foam Roofs
-One coat of GacoFlex 5-20 applied at a minimum rate of 1.5 gal/1001112
-Two (2) coats (base and top) of GacoFlex 5-20 applied at a minimum
rate of 0.75 gat/100ft2 per coat
GW18002 FL14724-R4 Page 3 of 6
This evaluation report is provided for State of Florida product approval under Rule 61G20-3. The manufacturer shall notify CREEK
Technical Services. LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, installation, recommended use, or other product attributes that are not
specifically addressed herein.
CREEK
TECHNICAL SERVICES, LLC
GACO WESTERN, LLC
GacoFlex Roof Coatings
Application of GacoFlex 5-21
Substrate
Minimum Application Rate
New or Existing)
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/100 ft'
followed by one of the following:
APP Modified Bitumen Membranes - Granule -surfaced
-One coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/100112
-Two (2) coats (base and lop) of GacoFlex S-21 applied at a minimum
rate of 0.75 gal/100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gat/100 ft'
followed by one of the following:
EPDM Single -Ply Membranes
-One coal of GacoFlex S-21 applied at a minimum rate of 1.5 ga1110011'
-Two (2) coals (base and top) of GacoFlex 5-21 applied at a minimum
rate of 0.75 gaU100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/100 ft2
followed by one of the following:
Galvanized Steel Metal Panels
-One coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/t00ft2
-Two (2) coats (base and top) of GacoFlex 5-21 applied at a minimum
rate of 0.75 gal/100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gaI1100 11:2
followed by one of the following:
Hypalon Single -Ply Membranes
-One coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/100ft2
-Two (2) coats (base and top) of GacoFlex 5-21 applied at a minimum
rale of 0.75 gaV100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gal/100 ft2
followed by one of the following:
KEE Single -Ply Membrane
-One coat of GacoFlex S-21 applied at a minimum rale of 1.5 gal/100ft2
-Two (2) coats (base and top) of GacoFlex 5-21 applied at a minimum
rate of 0.75 gal/100112 per coat
Primed with GacoFlex E-5320 Primer at a rale of 0.3 gaU100 ft2
followed by one of the following:
PVC Single -Ply Membranes
-One coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/100ft2
-Two (2) coats (base and top) of GacoFlex 5-21 applied at a minimum
rate of 0.75 gal/100f12 per coat
Primed with GacoFlex E-5320 Printer at a rate of 0.5 gal/100 W
followed by one of the following:
SBS Modified Bitumen Membranes - Granule -surfaced
-One coal of GacoFlex S-21 applied at a minimum rate of 1.5 ga11100ft2
-Two (2) coats (base and top) of GacoFlex S-20 applied at a minimum
rate of 0.75 gaV100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/100 ft2
followed by one of the following:
SBS Modified Bitumen Membranes - Smooth -surfaced
-One coat of GacoFlex 5-21 applied at a minimum rate of 1.5 gal/100ft2
-Two (2) coats (base and top) of GacoFlex S-20 applied at a minimum
rate of 0.75 gaU100ft2 per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gaV100 ft2
followed by one of the following:
TPO Single -Ply Membranes
-One coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/100112
-Two (2) coats (base and top) of GacoFlex S-21 applied at a minimum
rate of 0.75 gaV100ft2 per coat
Applied according to one of the following:
Spray Polyurethane Foam Roofs
-One
(coat of GacoFlex S-21 applied at a minimum rate of 1.5 gal/100ft2
1(2)
-Two
coats (base and top) of GacoFlex 5-21 applied at a minimum
rate of 0.75 gal/100ft2 per coat
GW18002 FL14724-R4 Page 4 of 6
This evaluation report is provided for State of Florida product approval under Rule 61G20-3. The manufacturer shall notify CREEK
Technical Services, LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, installation, recommended use, or other product attributes that are not
specifically addressed herein. I
GREEK
TECHNICAL SERVICES, LLC
GACO WESTERN, LLC
GacoFlex Roof Coatings
Application of GacoRoof GR -16
Substrate
New or Existing)
Minimum Application Rate
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gaill00 ft'
followed by one of the following:
Acrylic Coatings
-One coat of GacoRoof GRA6 applied at a minimum rate of 2 ga11100ft2
-Two (2) coats (base and top) of GacoRoof GR -16 applied at a minimum
rale of 1 gal/100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.4 gal/1 00 ft'
followed by one of the following:
BUR Membranes - Smooth -surfaced
-One coat of GamRoof GR -16 applied at a minimum rate of 2 gaV100ft2
-Two (2) coats (base and top) of GacoRoof GR -16 applied at a minimum
rate of 1 ga1110011' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 gaV100 ft'
followed by one of the following:
EPDM Single -Ply Membranes
-One coat of GacoRoof GR -16 applied at a minimum rate of 2 gall100fl'
-Two (2) coats (base and top) of GacoRoof GR -16 applied at a minimum
rate of 1 gal/100ft' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.3 ga1I100 ft'
followed by one of the following:
Galvanized Steel Metal Panels
-One coat of GacoRoof GR -16 applied at a minimum rate of 2 gaVlooft2
-Two (2) coats (base and top) of GacoRoof GRA6 applied at a minimum
rate of 1 gal/100ft' per coat
Primed with GacoFlex E5320 Primer at a rate of 0.3 gaV100 ft'
followed by one of the following:
KEE Single -Ply Membrane
-One coat of GacoRoof GRA6 applied at a minimum rale of 2 gal/100ft'
-Two (2) coats (base and top) of GacoRoof GRA6 applied at a minimum
rate of 1 gal/10011' per coat
Primed with GacoFlex E-5320 Primer at a rale of 0.3 gal/100 ft'
followed by one of the following:
PVC Single -Ply Membranes
-One coat of GacoRoof GRA6 applied at a minimum rate of 2 gal/100ft2
-Two (2) coats (base and top) of GamR00f GRA6 applied at a minimum
rate of 1 gal/10011' per coat
Primed with GacoFlex E-5320 Primer at a rate of 0.5 gal/100 ft'
followed by one of the following:
SBS Modified Bitumen Membranes - Granule -surfaced
-One coat of GacoRoof GRA6 applied at a minimum rale of 2 gal/1 OOft'
-Two (2) coats (base and top) of GacoRoof GR -16 applied at a minimum
rate of 1 gal/10011' per coat
Applied according to one of the following:
Spray Polyurethane Foam Roofs
-One coat of GacoRoof GRA6 applied at a minimum rate of 2 gal/100ft'
-Two (2) coats (base and top) of GacoRoof GRA6 applied at a minimum
rate of 1 gal/100ft' per coat
GW18002 FL14724-R4 Pads 5 of 6
This evaluation report is provided for State of Florida product approval under Rule 61G20-3. The manufacturer shall notify CREEK
Technical Services, LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, installation, recommended use, or other product attributes that are not
specifically addressed herein.
®CREEK
TECHNICAL SERVICES, LLC
LIMITATIONS
GACO WESTERN, LLC
GacoFlex Roof Coatings
1. Fire classification is not within the scope of this evaluation.
2. Structural integrity of the roofing substrate or assembly is not within scope of this evaluation. Refer to the
appropriate product approval for installation of these components within an Approved roof assembly.
3. Installation of the evaluated products shall be in strict compliance with this evaluation report, the FBC, and
the manufacturer's published installation instructions. In the event of conflict, the more restrictive and FBC
compliant installation shall be enforced.
4. This product shall not be applied in inclement weather conditions.
5. This product shall not be applied over asphaltic shingles, metal shingles, fiber -cement shingles, quarry slate,
cement or clay roofing tile, or wood shingles or shakes.
6. This product may be used may be used as described in other current FBC product approval documents.
7. Refer to manufacturer's published instructions for proper storage and shelf life considerations.
8. All products listed in this report shall be manufactured under a quality assurance program in compliance with
Rule 61 1320-3.
COMPLIANCE STATEMENT
The products evaluated herein by Zachary R. Priest have demonstrated compliance with the Florida Building Code,
61° Edition (2017) as evidenced in the referenced documents submitted by the named manufacturer.
011111111111 R
?, ENS
No 74021 = 2018.04.19
17:46:35
STATE O
-04'00'
:O•<u:
IK%c( O R 10P'����`� Zachary R. Priest, P.E.
�Of, S;ONA�?�`�` Organization No. ANE9641Florida Registration No. 021
CERTIFICATION OF INDEPENDENCE
CREEK Technical Services, LLC does not have, nor wilt it acquire, a financial interest in any company manufacturing or distributing
products under this evaluation.
CREEK Technical Services, LLC is not owned, operated, or controlled by any company manufacturing or distributing products under
this evaluation.
Zachary R. Priest, P.E. does not have, nor will acquire, a fine ncial Interest in any company manufacturing or distributing products
under this evaluation.
Zachary R. Priest, P.E. does not have, nor wit acquire, a fina4ial interest in any other entity involved in the approval process of the
product.
GW18002
END OF REPORT
FL.14724-R4
This evaluation report is provided for State of Florida product approval under Rule 611320-3. The manufacturer shall notify CREEK
Technical Services, LLC of any product changes or quality assurance changes throughout the duration for which this report is valid.
This evaluation report does not express nor imply warranty, installation, recommended use, or other product attributes that are not
specifically addressed herein.
INSPECTION SEQUENCE
BP# 18-4355
ADDRESS: 4355 St. Johns Pkwy
BUILDING PERMIT
Min Max Inspection Description
Footer / Setback
Stemwall
Slab / Mono Slab
Lintel / Tie Beam / Fill / Down Cell
Sheathing — Walls
Sheathing — Roof
Roof D In
Frame
Insulation Rough
Firewall Screw Pattern
Drywall / Sheetrock
Lath Inspection
Building Ceiling Air Barrier
Insulation Roof (Com'l)
Building Ceiling Grid
1000 Final Roof
Final Stucco / Siding
Final Insulation
Final Firewall
Final Door
Final Window
Final Utility Building
Final Screen Structure
Final Pool Screen Enclosure
Pre -Demo
Final Demo
Final Single Family Residence
Final Commercial —
Final Commercial — Addition / Alteration
Final Commercial — Change of Use
Final Building (Other)
REVISED: June 2014
ELECTRICAL PERMIT
Min Max Inspection Description
Electric Underground
Footer / Slab Steel Bond
Electric Ceiling Rough
Electric Wall Rough
Electric Rough
Pre -Power Final
Temporary Pole
Electric Final
PLUMBING PERMIT
Min Max Inspection Description
Rough Plumb
Plumbing Underground
Plumbing 2"d Rough
Plumbing Tubset
Plumbing Sewer
Plumbing Grease Trap Rough
Plumbing Steam / Chill Water Rough
Plumbing Final
MECHANICAL PERMIT
Min Max Inspection Description
Mechanical Rough
Mechanical Fire Damper Framing
Mechanical Ceiling Rough
Mechanical Fire Damper Annular Space
Mechanical Insulation Wrap
Mechanical Fire Damper Angle
Light / Water Test Ck Welds
Mechanical Grease Duct Wrap
Mechanical Final