Loading...
HomeMy WebLinkAbout2557 IFB 22/23-21 Sanford North WRF & South WRC Electrical Sys Improvements - (Perf Bond)Bond No. 30BCSJB0860 GRANT MALOY, SEMINOLE COUNTY SECTION 00605 CLERK OF CIRCUIT COURT & COMPTROLLER CFN# 2024037624 Bk:10619 Pg:777-790(14Pgs) REC: 04/29/2024 2:11:08 PM by cjones PERFORMANCE BOI RECORDING FEES $120.50 (100% of Contract Pri( Project Name: Sanford North WRF and South WRC Electrical System Improvements Name: Address Phone No. City Contract No.: IFB No. 22/23-21 Contractor Eau Gallie Electric. Inc. 2012 Aurora Road Melbourne, FL 32935 321-259-2885 Owner Name: City of Sanford Address: 300 N. Park Ave. Sanford, FL. 32771 Surety Hartford Fire Insurance One Hartford Plaza Hartford, CT 06155 (860) 547-5000 Phone No.: 407-688-5028 KNOW ALL MEN BY THESE PRESENTS that The above named Contractor, as Principal, and the above named Surety, as SURETY, are held and firmly bound unto the Owner, the City of Sanford, a Political Subdivision of the State of Florida, in the full and just sum of $1,186,000.00, lawful money of the United States of America, to the payment of which sum, well and truly to be made, the Contractor and SURETY bind themselves, their representatives, and each of their heirs, executors, administrators, successors and assigns, jointly and severely, firmly by these presents. The Project is located at: 1201 W Seminole Blvd. Sanford FL 32771 and 3540 Cameron Ave Sanford FL 32771 General description of the Work: Sanford North WRF: The Project consists of the purchase of Switchboard Stvle Main Breakers, Automatic Transfer Switches, Power Distribution Switchboards, and all equipment and incidentals required for the complete electrical system. Sanford South WRC: This Project consists of installation of Owner purchased switchgear, switchgear modifications and additions, conduit/wire and all equipment and incidentals required for the complete electrical system. This project also consists of furnishing and installing a temporary qenerator with new conduit/wire_ from the temporary generator to the existing 1600 - amp ATS VVHEREA.S, the Contractor has by written Agreement dated , entered into a Contract with the Owner for IFB No. 22/23-21, for the project entitled Sanford North WRF and South WRC Electrical System Improvements Sanford North WRF and South WRC PERFORMANCE BOND Electrical System Improvements (100% of Contract Price) 00605-1 with conditions and provisions as are further described in the aforementioned Agreement, which Agreement is by reference made a part hereof for the purpose of explaining this bond. NOW, THEREFORE, the condition of this obligation is such that if Principal: Promptly and faithfully performs its duties, all the covenants, terms, conditions, and agreements of said Contract including, but not limited to the insurance provisions, guaranty period and the warranty provisions, in the time and manner prescribed in the Contract, and Pays Owner all, losses, damages, delay damages (liquidated or actual), expenses, costs and attorneys' fees, including costs and attorney's fees on appeal that Owner sustains resulting directly or indirectly from any breach or default by Principal under the Contract, then this bond is void; otherwise it shall remain in full force and effect. Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner having performed Owner's obligations thereunder, the SURETY shall promptly remedy the default or shall promptly: A. Complete the Contract in accordance with its terms and conditions; or B. Expeditiously obtain a bid or bids for completing the Contract in accordance with its terms and conditions, and upon determination by SURETY of the lowest responsible qualified bidder, award a contract; or, if the Owner elects, upon determination by the Owner and the SURETY jointly of the lowest responsible bidder, to have the SURETY arrange for a contract between such bidder and Owner, and for the SURETY to make available as Work progresses sufficient funds to pay the cost of completion less the balance of the Contract price (even though there should be a default or a succession of defaults under the contract or contracts of completion arranged under this paragraph). The term "balance of the Contract price," as used in this Bond, shall mean the total amount payable by Owner to Contractor under the Contract and any approved change orders thereto, less the amount properly paid by Owner to Contractor. The SURETY shall pay Owner all remaining losses, delay and disruption damages, expenses, costs, and statutory attorney's fees, including appellate proceedings, that Owner sustains because of a default by Contractor under the Contract. 2. Any changes in or under the Contract Documents (which include the Plans, Drawings, and Specifications) and compliance or noncompliance with any formalities connected with the Contract or the changes therein shall not affect SURETY's obligations under this Bond and SURETY hereby waives notice of any such changes. 3. The SURETY's monetary obligations to the Owner shall not be reduced by legal fees and costs incurred by the SURETY arising out of Contractor's default. 4. The SURETY, for value received, hereby stipulates and agrees that its obligations hereunder shall be direct and immediate and not conditional or contingent upon Owner's pursuit of its remedies against Principal, shall remain in full force and effect notwithstanding Sanford North WRF and South WRC PERFORMANCE BOND Electrical System !mprovements (100% of Contract Price) Cit&05-2 (i) amendments or modifications to the Contract entered into by Owner and Principal without the SURETY's knowledge or consent (ii) waivers of compliance with terms of the Contract granted by Owner to Principal without the SURETY's knowledge or consent, or (iii) the discharge of Principal from its obligations under the Contract as a result of any proceeding initiated under the Bankruptcy Code of 1978, as the same may be amended, or any similar state or federal law, or any limitation of the liability of Principal or its estate as a result of any such proceeding. 5. The Surety shall indemnify and hold the Owner harmless from any and all claims and damages, arising from the Contractor's default under the Contract including, but not limited to, contractual damages, expenses, costs, injury, negligent default, or intentional default, patent infringement and actual damages in accordance with the Contract. 6. In the event that the SURETY fails to fulfill its obligations under this Performance Bond, then the SURETY shall indemnify and hold the Owner harmless from any and all loss, damage, cost and expense, including reasonable attorneys' fees and costs for all trial and appellate proceedings, resulting from the SURETY's failure to fulfill its obligations hereunder. This paragraph shall survive the termination or cancellation of this Performance Bond. 7. The Contractor shall save the Owner harmless from any and all damages, expenses and costs which may arise by virtue of any defects in said work or materials within a period of two (2) years from the date of Final Completion of the Project. 8. This Performance Bond is intended to comply with the requirements of Section 255.05, Florida Statutes, as amended, and additionally, to provide contract rights more expansive than as required by statute. IN WITNESS WHEREOF, this instrument is executed this 13th day of February . 2024 ATTEST.- By: Secretary hes yo ed Name -:�COfFflRA,7E $EAL) "(Wi n ss C ACT R) Typed or Printed Name Kim A. Lankarn Sanford North WRF and South WRC Electrical System Improvements PRINCIPAL/CONTRACTOR Eau Gallie Electric, Inc. PRINCIPAL / CONTRACTOR a, /1,/, By: CONTRACTOR Signatory Authority WrIWR) r Ad cthe,5 Pre . Typed or Prinked Name anWTitle 2012 Aurora Road Address Melbourne, FL 32935 City, State, Zip 00605-3 321-259-2885 PERFORMANCE BOND (100% of Contract Price) (Witness o CONTRACTOR) Typed or PrintedAame Cot R . Der -`R3 ss ATTEST: ,�b- (SU ETY) Secretary Laura L. Brown Typed or Printed Name �i Witness as "Z,/- S6RETY Mattin Typed or Printed Name N/A Witness as to SURETY N/A Typed or Printed Name Telephone No. Facsimile No. 5,21-J69- 618S5 Y--103 SURETY Hartford Fire Insurance Company SURETY By: �,;A, —77 Mai -Ling Rodriguez Typed or Printed Name Attorney -In -Fact Title 555 Fairmount Avenue Address Baltimore, MD 21286 City, State, Zip 410-339-1209 N/A Telephone No. Facsimile No. NOTE: Date of this Performance Bond must not be prior to date of the Agreement. If CONTRACTOR is a joint venture, all ventures shall execute this Performance Bond. If CONTRACTOR is a Partnership, all partners shall execute this Performance Bond. IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570, as amended) and be authorized to transact business in the State of Florida, unless otherwise specifically approved in writing by Owner. All bonds shall be originals and issued or countersigned by a local producing agent who is authorized to operate in the State of Florida. Attorneys -in -fact who sign Bid Bonds or Performance/Payment Sanford North WRF and South WRC Electrical System Irr.provements 00605-4 PERFORMANCE BOND (100% of Contract Price) Bonds must file with such bond a certified copy of their Power of Attorney to sign Such Bond. Agents ef surety companies must list their name, address, and telephone number on all Bonds. Sanford North WRF and South WRC Electrical System Improvements END OF SECTION 00605-5 PERFORMANCE BOND (100% of Contract Price) Bond No. 3OBCSJB0860 SECTION 00610 PAYMENT BOND (100% of Contract Price) Project Name: Sanford North WRF and South WRC Electrical System Improvements City Contract No.: IFB No. 22/23-21 Contractor Surety Name: Eau Gallie Electric, Inc. Hartford Fire Insurance Company Address: 2012 Aurora Road One Hartford Plaza Melbourne, FL 32935 Hartford, CT 06155 Phone No.: 321-259-285 Owner Name: City of Sanford Address: 300 N. Park Ave. Sanford, FL. 32771 Phone No.: 407-688-5028 KNOW ALL MEN BY THESE PRESENTS that (860) 547-5000 The above named Contractor, as Principal, and the above named Surety, as SURETY, are held and firmly bound unto the Owner, the City of Sanford, a Political Subdivision of the State of Florida, in the full and just sum of $1,186,000.00, lawful money of the United States of America, to the payment of which sum, well and truly to be made, the Contractor and SURETY bind themselves, their representatives, and each of their heirs, executors, administrators, successors and assigns, jointly and severely, firmly by these presents. The Project is located at: 1201 W Seminole Blvd. Sanford FL 32771 and 3540 Cameron Ave Sanford FL 32771 General description of the Work: Sanford North WRF: The Project consists of the purchase of Switchboard Stvle Main Breakers. Automatic Transfer Switches. Power Distribution Switchboards, and all equipment and incidentals required for the complete electrical system. Sanford South WRC: This Project consists of installation of Owner purchased switchgear, switchgear modifications and additions, conduit/wire and all equipment and incidentals required for the complete electrical system. This project also consists of furnishing and installing a temporary generator with new conduit/wire from the temporary qenerator to the existing 1600 - amp ATS. Sanford North WRF and South WRC PAYMENT BOND Electrical System Improvements (100% of Contract Price) 00610-1 WHEREAS, the Contractor has by written Agreement dated , entered into a Contract with the Owner for IFB No. 22/23-21, for the project entitled Sanford North WRF and South WRC Electrical System Improvements, with conditions and provisions as are further described in the aforementioned Agreement, which Agreement is by reference made a part hereof for the purpose of explaining this bond. NOW, THEREFORE, the condition of this obligation is such that if Principal shall promptly make payments to all claimants as defined in Section 255.05(1), Florida Statutes, supplying Principal with labor, Materials, or supplies, used directly or indirectly by Principal in the prosecution of the Work provided for in the Agreement, then this obligation shall be void; otherwise, it shall remain in full force and effect subject, however, to the following conditions: This Payment Bond is furnished for the purpose of complying with the requirements of Section 255.05, Florida Statutes, as same may be amended. 2. Any action instituted by a claimant under this Bond for payment must be in accordance with the notice and time limitation provisions in Sections 255.05(2) and 255.05(l 0), Florida Statutes. 3. This Payment Bond is conditioned that Contractor shall promptly make payments to all persons defined in Section 713.01, Florida Statutes, whose claims derive from the prosecution of the Work provided for in the Contract. 4. Pursuant to Section 255.05, Florida Statutes, a claimant, except a laborer, who is not in privity with the Contractor shall, before commencing or not later than forty-five (45) days after commencing to furnish labor, services, or materials for the prosecution of the Work, serve the contractor with a written notice that he or she intends to look to the Bond for protection. A claimant who is not in privity with the Contractor and who has not received payment for furnishing his or her labor, services, or materials shall serve a written notice of nonpayment on the Contractor and on the SURETY. The notice of nonpayment shall be under oath and served during the progress of the Work or thereafter but may not be served earlier than forty-five (45) days after the first furnishing of labor, services, or materials by the claimant or later than ninety (90) days after the final furnishing of the labor, services, or materials by the claimant or, with respect to rental equipment, later than ninety (90) days after the date that the rental equipment was last on the job site available for use. 5. The time periods for service of a notice of nonpayment or for bringing an action against a Contractor or a Surety shall be measured from the last day of furnishing labor, services, or materials by the claimant and may not be measured by other standards, such as the issuance of a certificate of occupancy or the issuance of a certificate of substantial completion. 6. An action, except an action for recovery of retainage, must be instituted against the Contractor or the SURETY on the payment bond within one (1) year after the performance of the labor or completion of delivery of the materials or supplies. An action for recovery of retainage must be instituted against the Contractor or the SURETY within one (1) year after the performance of the labor or completion of delivery of the materials or supplies. Sanford North VVRF and South VVRC Electrical System lmarovements 00610-2 PAYMENT BOND (900% of Contract Price) 7. The claimant shall have a cause of action against the Contractor and SURETY for the amount due him or her, including unpaid finance charges due under the claimant's contract. Such action may not involve the Owner in any expense. 8. Any changes in or under the Contract or Contract Documents and compliance or non- compliance with any formalities connected with the Contract or the changes therein shall not affect SURETY's obligations under this Payment Bond and SURETY hereby waives notice of any such changes. Further, Principal and SURETY acknowledge that the sum of this Payment Bond shall increase or decrease in accordance with the Change Orders (unilateral or directive change orders and bilateral change orders) or other modifications to the Contract or Contract Documents. This Payment Bond shall not cover any components or materials directly purchased and paid for by the Owner. 9. The Performance Bond and this Payment Bond and the covered amounts of each are separate and distinct from each other. This Payment Bond shall be construed as a statutory Payment Bond under Section 255.05, Florida Statutes, and not as a common law bond. IN WITNESS WHEREOF, this instrument is executed this 13th day of February , 2024 ATTEST: By: Secretary iwbcr1-l�j Typzd o:r Pri" ed Name of SeJetary (CGRP(ORATE SEAL) Witness to CONTRACTOR g rn A. La intra",\ Typed Nam (Witness to CO RACTOR) Care,k R . T e-,�L) ---is Typed or Pri ted Name Sanford North WRF and South WRC Electrical System Improvements PRINCIPAL/CONTRACTOR Eau Gallie Electric, Inc. PRINCIPAL / CONTRACTOR By: CONTRACTOR Signatory Authority Typed or Printed Name and Title 2012 Aurora Road Address Melbourne, FL 32935 City, State, Zip 321-259-2885 X l u3 Telephone No. Facsimile No. 111114 M11 PAYMENT BOND (100% of Contract Price) ATTEST: (SURETY) Secretary Laura L. Brown Typed or Printed Name F -V ' 101do �J i3 Hossay Mattin Typed or Printed Name N/A Witness as to SURETY N/A Typed or Printed Name SURETY Hartford Fire Insurance Company':; SURETY 3 - By: L ' Mai -Ling Rodriquez Typed or Printed Name Attorney -In -Fact Title 555 Fairmount Avenue Address Baltimore, MD 21286 City, State, Zip 410-339-1209 N/A Telephone No. Facsimile No. NOTE: Date of this Payment Bond must not be prior to date of the Agreement. If CONTRACTOR is a joint venture, all ventures shall execute this Payment Bond. If CONTRACTOR is a Partnership, all partners shall execute this Payment Bond. IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570, as amended) and be authorized to transact business in the State of Florida, unless otherwise specifically approved in writing by Owner. All bonds shall be originals and issued or countersigned by a local producing agent who is authorized to operate in the State of Florida. Attorneys -in -fact who sign Bid Bonds or Performance/Payment Bonds must file with such bond a certified copy of their Power of Attorney to sign such Bond. Agents of suret<j companies must list their name, address, and telephone number on all Bonds. Sanford North WRF and South WRC Electrical System Improvements U11ZOI---:1AIIIIII:Eel E 00610-4 PAYMENT BOND (100% of Contract Price) Direct Inquiries/Claims to: THE HARTFORD P�T"U"RNEY BOND,T-11 One Hartford Plaza v, IF It Hartford, Connect cut 06155 Bond.Claimsft-thehartford.com call: 888-266-3488 or fax: 860-757-5835 KNOW ALL PERSONS BY THESE PRESENTS THAT: Agency Name: RCM & D INC Agency Code: 30-727000 0 '1a:'tford Fire Insurance Company, a corporation duly organized under the laws ofthe State of Connecticut C] Hartford Casualty Insurance Company, a corporation duly organized under the laws ofthe State of Indiana Hartford Accident and Indemnity Company, a corporation duly organized under the laws ofthe State of Connecticut Hartford Underwriters Insurance Company, a corporation duly organized under the laws ofthe State of Connecticut Twin City Fire Insurance Company, a corporation duly organized under the laws ofthe State of Indiana C� Hartford insurance Company of Illinois, a corporation duly organized under the laws ofthe State of Illinois Hartford Insurance Company of the Midwest, a corporation duly organized under the laws ofthe State of Indiana Hartford insurance Company of the Southeast, a corporation duly organized under the laws ofthe State of Florida having their home office in Hartford, Connecticut, (hereinafter collectively referred to as the "Companies") do hereby make, constitute and appoint, up to the amount of Unlimited : Laura L. Brown, Robert T. Cawley, Stephen J. Mainello, Hossay Mattin, Mai -Ling Rodriguez, Lori A. Rupp, Rush H. Seale of BALTIMORE, Maryland their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as delineated above by ©, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on May 23, 2016 the Companies have caused these presents to be signed by its Assistant Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary. Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are and will be bound by any mechanically applied signatures applied to this Power of Attorney. �'svl�Wa � YtLIA' � �ce•� .s��tia+�dr � �.��_�- ._.� "��;�+a`•:�c•...r�s '� 8 R�.. 's/+'/�••t'•.'ot+.�r.�T.�+��°rw9�'4�9!�}e•4c<�e 5t�.: �9.m.'.�7/va9rra.:q'�•���. w5.gg'7- i �+'hussris msa Yy''•gc^ Shelby Wiggins, Assistant Secretary STATE OF FLORIDA ss. Lake Mary COUNTY OF SEMINOLE On this 20th day of May, 2021, before me personally came Joelle LaPierre, to me known, who being by me duly sworn, did depose and say: that (s)he resides in Seminole County, State of Florida; that (s)he is the Assistant Vice President of the Companies, the corporations described in and which executed the above instrument; that (s)he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that they were so affixed by authority of the Boards of Directors of said corporations and that (s)he signed his/her name thereto by like authority. •'0" Jessica Ciccone OF gt�.' My Commission HH 122280 Expires June 20, 2025 I, the undersigned, Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is still in full force effective as of February 13, 2024 Signed and sealed in Lake Mary, Florida. j 026-1. Ole ''`• •':co°r*4' 01 ._ n"7A 1879 f�; 1979.,� • ..,, tlltratS� r e,u• ~`"•Ro Joelle L. LaPierre, Assistant Vice President Keith D. Dozois, Assistant Vice President Wd£h:6 9002/ZOAL b01b0 �c d IH9IS6W ' NI -A Md 9E6Z886898 Lb : t0 908,/6t/BZ e,nn /Inn I nv nn�ry ivn 7nr7 ii�c nno vva or. • nT nnn7 /7n /TT N a LLI .0 m = cu 0 Co cn C •_ a) a�a� m--.mZ U •O uia -C ® �0 0-0 aN 0))( tic 0 yN C) l.L,. t3' U U co _ •—s -3 � _- ) 70 0 vi o 0 m:E co 0 � � H en U rn v ® o Z b01b0 �c d IH9IS6W ' NI -A Md 9E6Z886898 Lb : t0 908,/6t/BZ e,nn /Inn I nv nn�ry ivn 7nr7 ii�c nno vva or. • nT nnn7 /7n /TT N U — U O O G — T .r O _ U U r � L U V1 W N N N N N N 2m Q O O O y u c m c w N N N Er >> E a u w, (3)(T) 0) N T p N n O T C)C)0') m c m O O O n p c c o Qo J m E a o v J Joo O aci C F RSN O J c O� c N o 0. a c m c N d U u 1� 1cuC O L (n E p V N � p N� C Cp O C C N f0 n L d J n V u L pW _� "-- N UO N U L C = p '2 W E d C O >. E O O • %+ O E C .... 0• 0 0 aVJ � U i 3 a o p p Cc U p D N U o � O U C C r U rn o •F' U cVw] O " ° E E ~ 70 U c w m m E m r O O n C U 0 — •� QD p C N U LL T upi ' O U d m L p E v aci LL d 11 C > L N fn C U W C Q U 0 m L o p U o A w ac E U) U) z06/� U L J V¢ N U �� W Uo V/ W �xQ a— �z U N L LL J p V moDN��oo A Di W �/ L.I^... Q /W Q Q L p 2Sz C m V Q Q m 'O (V L 9 5 /v VA O N N LL C J N u > ro OLu WJ Z •C/) P: E -J •� C OU A O M~ N J i o �' -p y .� Q o 3 Qf z z W O i= c16v W W C) -C EEN`omo�� 0/� � �(D F-- N Q o V J p O N U3 % VJ V J }' W W ) ; a z z e 5 s 0o z z z r o CO LO N N ® O O O y Y � U 00 Q O Q J O C,: F N O F01 F- Q W rn O v b T o fU., Y 7b00 U � �_ Q) � Q � v pA [� p C, F- Q v 5 r� : p o RCM' -.0 February 13, 2024 Kim A. Lanham Eau Gallie Electric, Inc. 2012 Aurora Road Melbourne, FL 32935 555 Fairmount Avenue Phone 410.339.7263 www.rcmd.com Baltimore, MD 21286 Fax 410.339.7234 Toll -Free 800.346.4075 Direct Dial: 410.399.1209 Email: mrodriguez@rcmd.com Re: Bond No. 30BCSJB0860 — City of Sanford — $1,186,000 Dear Kim, Enclosed please find the above captioned Performance and Payment bonds, executed per your request. The bond must be signed by an authorized representative of your company, notarized (if required) and sealed with the corporate seal. We urge you to double-check all signatures, dates, amounts and job descriptions for accuracy. This will avoid the possibility of having the bond rejected by the Obligee. Please verify again that the bond form we executed is the form required by the specification. In addition, please verify that any special requirements for the bond issuance that is required by the obligee is also attached. NOTE: The enclosed bond will precede the contract. All contract terms, conditions, schedule and scope must be agreed upon and all parties should sign final contract prior to giving the bond to obligee. All requests to place or change coverage, including bond penal sum, will be confirmed in writing and approved/agreed to by the surety. Coverage should not be considered bound until you have received such confirmation. Please forward a fully executed copy of the contract at your earliest convenience, if not already done so. Feel free to call our office if you should have any questions or need any further assistance. Sincerely, a' % R ri uez g g Client M ager A wAPY U CS COURr y,0 Grant Maloy Clerk of the Circuit Court & Comptroller Seminole County P.O. Box 8099 �\� Sanford FL 32772 Phone:407-665-4327 Customer: SANFORD, CITY P O BOX 1788 SANFORD F Tran: 5589669 - 95186428 Receipt # 2331745 Receipt Date 04/29/2024 Account No: 116 Account Balance: 1,024.50 1 BOND Inst# 2024037624 BKPG 10619/777 BOND $120.50 COUNTY RECORDING FEES 120.50 Receipt Total: $120.50 Paid By: CHARGE MANSOL ORDONEZ./PURCHASING DEPT 120.50 Total Tendered $120.50 HAVE A NICE DAY HOW ARE WE DOING? PLEASE VISIT SEMINOLECLERK.ORG Printed: 04/29/2024 2:11 pm Rec By: cjones ver. 19.08.26.1001 E L E C T R 1 C SIIIC�4� DATE: 2-27-24 This Instrument Prepared By & Return To: Ms. Marisol Ordonez TO: Kim Searles Purchasing Manager/City Hall 300 N. Park Ave., Sanford Fl. 32771 FROM: Kim Lanham PROJECT: Sanford North WRF & South WRC Electrical Improvements RE: Payment & Performance Bonds Good afternoon. Enclosed, please find the original signed and sealed Payment and Performance Bonds for the project named above. As requested, the date was left blank. Please contact me if you have questions or need additional information. Thank you, Kim 2012 Aurora Road 1 Melbourne, FL 32935 T (321) 259-2885 1 F (321)254-1518 1 1-877-434-5577 EG-Electric.com