HomeMy WebLinkAbout412 South Oak AveCITY OF SANFORD
BUILDING & FIRE PREVENTION
PERMIT APPLICATION
Application No: Y- 13 g ,_�
Documented Construction Value: $ 5,750.00
Job Address: 412 South Oak Avenue Sanford, FL 32771 Historic District: Yes ❑ No 0
Parcel ID: 25-19-30-5AG-0605-003A Residential ® Commercial ❑
Type of Work: New 0 Addition ❑ Alteration ❑ Repair ❑ Demo ❑ Change of Use ❑ Move ❑
Description of Work: Re -Roof Tamko Elite 3 -tab shingles 25sq
Plan Review Contact Person: Kelly MCAvoy Title: Office
Phone: 407-960-2611
Name Yoram Yahav
Street: 412 S. Oak Avenue
Fax: 407-960-2612
City, State Zip: Sanford, FI 32771
Email: briansikesroofing@cfl.rr.com
Property Owner Information
Phone: 407-625-0635
Resident of property? :
Contractor Information
Name Brian Sikes Phone: 407-960-2611
Yes
Street: 1550 S Hwy 17 92 Fax: 407-960-2612
City, State Zip: Longwood, FI 32750 State License No.: CCC1325977
Architect/Engineer Information
Name: Phone:
Street: Fax:
City, St, Zip:
Bonding Company:
Address:
E-mail:
Mortgage Lender:
Address:
WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR
PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE
RECORDED AND POSTED ON THE JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN
FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE, RECORDING YOUR NOTICE; OF
COMMENCEMENT.
Application is hereby made to obtain a permit to do the work and installations as indicated. I certify that no work or installation has
commenced prior to the issuance of a permit and that all work will be performed to meet standards of all laws regulating construction
in this jurisdiction. 1 understand that a separate permit must be secured for electrical work, plumbing, signs, wells, pools,
furnaces, boilers, heaters, tanks, and air conditioners, etc.
FBC 105.3 Shall be inscribed with the date of application and the code in effect as of that date: 5t° Edition (2014) Florida Building Code
Revised: June 30, 2015 Permit Application
NOTICE: In addition to the requirements of this permii, there may be additional restrictions applicable to this property that may be
found in the public records of this county, and there may be additional permits required from other governmental entities such as water
management districts, state agencies, or federal agencies.
Acceptance of permit is verification that 1 will notify the owner of the property of the requirements of Florida Lien Law, FS 713.
The City of Sanford requires payment of a plan review fee at the time of permit submittal. A copy of the executed contract is required
in order to calculate a plan review charge and will be considered the estimated construction value of the job at the time of submittal.
The actual construction value will be figured based on the current ICC Valuation Table in effect at the time the permit is issued, in
accordance with local ordinance. Should calculated charges figured off the executed contract exceed the actual construction value,
credit will be applied to your permit fees when the permit is issued.
OWNER'S AFFIDAVIT: I certify that all of the foregoing information is accurate and:that all work will
be done in compliance with all applicable laws regulating construction and zoning.
-IZ4 z b z
Signature of Owner/Agent I>atit Signature of Con r gent Date
r62,R'�l S•'
Print Cantdc—tor/AjEcWs Name
DINELIA I. t)OMINSKYNotey F�wk state a Florida
* * MY COMMISSION o FF 064147 a . Steven Catnpbell
EXPIRES. Febraary 18, 2018 • My � unlsston FF 990959
'Now 000900 1"Vow riNo"Sexlen F�plrsSoWi012020
a
Owner/Agent is ersonally Known to or Cont ent is,- Personally:Known to Me or
Produced LD Type of 1D Produced ID a of ID
BELOW IS FOR OFFICE USE ONLY
Permits Required: Building ❑ Electrical ❑ Mechanical ❑ Plumbing[] Gas[] Roof ❑
Construction Type:
Occupancy Use:
Flood Zone:
Total Sq Ft of Bldg: Min. Occupancy Load: # of Stories:
New Construction: Electric - # of Amps Plumbing - # of Fixtures
Fire Sprinkler Permit: Yes ❑ No ❑
APPROVALS. ZONING:
ENGINEERING:
COMMENT
# of Heads Fire Alarm Permit: Yes ❑ No ❑
UTILITIES: WASTE WATER:
?1 60 2SS1
BUILDING:
Ravised: lune 30.2015 Permit Application
12/6/2016
tz
keipl,PRAour+�v iaatm�
Parcel Information
SCPA Parcel View: 25-19-30-5AG-0605-003A
oerty Record Card
Pn rcol: 25 -19 -30 -SAG -0605-1)034
Owner:. CLAYTON HENRY E-8 MARILYN A
Property Address: 412 S OAK AVE SANFORD. FL 32771-1826
Value Summary
Parcel 25-19-30-5AG-0605-003A
Owner CLAYTON HENRY E 8 MARILYN A
Property Address 412 SOAK AVE SANFORD. FL 32771-1826
Mailing 412 S OAK AVE SANFORD, FL 32771-1826
Subdivision Name j SANFORD TOWN OF
Tax District I S1 -SAN FORD
DOR Use Code 1 0103-TOWNHOME
Exemptions 00-HOMESTEAD(1995)
Legal Description
PT LOTS 3 8 4 DESC AS BEG
150.023 FT S 8 53.083 FT W OF NE
COR BLK 6 TR 5 RUN W 37.083 FT S
46.083 FT E 37.083 FT N 46.083 FT
TO BEG BILK 6 TR 5
TOWN OF SANFORD
PB 1 PG 58
Taxes
Taxing Authority I Assessment Value
City Sanford
SJWM(Saint Johns Water Management)
County Bonds
County General Fund
Schools—
Sales
Tax Amount without SOH: $649.75
2016 Tim Bill Amount $535.81
Tax Estimator
Save Our Homes Savings: $113.94
' Does NOT INCLUDE Non Ad Valorem Assessments
Exempt Values
$71,210
$71,210
$71,210
$71,210
$71,210
2017 -Working
2016 Certified
$25,000
Values
Values
Valuation Method
i cost/Market
Cost/Market
Number of Buildings
I 1
1
Depreciated Bldg Value
$68,332
1
$65,877
Depreciated EXFT Value
02476
43Z
Land Value (Market)
$14,500
$14,500
Land Value Ag
5/1/1990
I
Just/Market Value "
$82,832
1$80,377
Portability Adj
TRUSTEE DEED
7/1/1987
Save Our Homes Adj
$11,622
J
$9,662
Amendment l Adj
I
WARRANTY DEED
P&G Adj
1$0
$0
-Assessod'Value
I $71.210
$70,715
Tax Amount without SOH: $649.75
2016 Tim Bill Amount $535.81
Tax Estimator
Save Our Homes Savings: $113.94
' Does NOT INCLUDE Non Ad Valorem Assessments
Exempt Values
$71,210
$71,210
$71,210
$71,210
$71,210
Descriptidn
Taxable Value
$46.210.
$25,000
$46,210
$25.000
$46,210
$25,000
$71,210
SO
$25,000
$46,210
Descriptidn
I Date
Book
Page
'Amount Oualified
VacAmp
WARRANTY DEED
6/1/1994
02782
.0843
$46,000 1 Yes
Improved
WARRANTY DEED
9/1/1992
02476
43Z
$52.500 Yes
Improved
TRUSTEE DEED
5/1/1990
02199
0709
$100 No
Improved
TRUSTEE DEED
7/1/1987
01873
1113
$100 No
Improved
WARRANTY DEED
4/1/1984
01539
0030
$50,700 Yes
Improved
Find Comparablo Saha
Land --- -
- --
- -
- - --- - -- — - -
-
-r
II
Method FroritageDepth
LOT
0.00
0.00
Units
Units Price
1 $14,500.00 ,
Land Value
$14,500
http://parceldeWl.scperll.org/ParcelDetaillydo.aspx?PID=2519305AG0605003A 1/2
THIS INSTRUMENT PREPARED BY:
Name: Saundra-Rosberg
Address: 1550 S Hwy 17 92
Longwood, FI 32750
NOTICE OF COMMENCEMENT
Permit Number:
Parcel ID Number. 25-19-30-5AG-0605-003A
Iltl�l II11� II@tl I�Il1 IIIII IIIII illi 1111
MARYANNE MORSEr SEMINOLE COUNTY
CLERK OF CIRCUIT COURT G COMPTROLLER
BY. 8823 P9 760 (1Pgs)
CLERK'S A 2016128857
RECORDED 12/13/2016 10:21:42 AM
RECORDING FEES $10.00
RECORDED BY hdevore
The undersigned hereby gives notice that improvement will be made to certain real property, and in accordance with Chapter 713, Florida Statutes, the
following Information is provided In this Notice of Commencement.
1. DESCRIPTION OF PROPERTY: (Legal description of the property and street address if available)
2. GENERAL DESCRIPTION OF IMPROVEMENT:
Re -Roof Tamko Elite 3 -tab Shingles 25sq
3. OWNER INFORMATION OR LESSEE INFORMATION IF THE LESSEE CONTRACTED FOR THE IMPROVEMENT:
Name and address: Yoram Yahav 412 S. Oak Avenue Sanford, FI 32771
Interest In properly: Owner
Fee Simple Title Holder Of other than owner listed above) Name:
Address:
4. CONTRACTOR: Name: Brian Sikes Phone Number: 407-878-3750
Address: 1550 S Hwy 17 92 Longwood, FI 32750
b. SURETY (If applicable, a copy of the payment bond Is attached): Name:
Address: Amount of Bond:
S. LENDER: Name: Phone Number:
Address:
7. Persons within the State of Florida Designated by Owner upon whom notice or other documents may be served as provided by Section
713.13(1)(a)7., Florida Statutes.
Name, Phone Number:
Address:
8. In addition, Owner designates of
to receive a copy of the Llenol's Notice as provided In Section 713.13(1)(b), Florida Statutes. Phone number:
8. Expiration Date of Notice of Commencement (The expiration Is 1 year from date of recording unless a different date Is specified)
WARNING TO OWNER: ANY PAYMENTS MADE BY THE OWNER AFTER THE EXPIRATION OF THE NOTICE OF COMMENCEMENT ARE
CONSIDERED IMPROPER PAYMENTS UNDER CHAPTER 713, PART I, SECTION 713.13, FLORIDA STATUTES, AND CAN RESULT IN YOUR
PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE
JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY
BEFORE COMMENCING WORK OR RECORDING YOUR NOTICE OF COMMENCEMENT,
(Slpnotum of Gamer Of Les leo, or Ownols a leasse's (PAN Nemo and Ptovido Slpnetory's TAW, lace)
AuUlahod OIIIeerlDlreclodPaMerRAenopeQ
04
State of iCYL --/ County of
The foregoing Instrument was acknowledged before me this
by
who has produced Identification O type of Identification produced:
DIMELIA L COMINSKY
MY COMMISSION 0 FF 064147
# * EXPIRES: February 16, 2018
N'��ior r eoedad my Wad Notary stivlaa
D&P 13 2016
day of , �—
Who is personally known tom OR
Q.C7*rr,1rz
) PY • MA YANNE MORSE . C ,:' l
C ic-UTT c1;1j1tT AND
SE . RIM ,r�hii�w
pY DEPUTY CLERIC
Brian Sikes
OOFIAGInc:DATE PROPOSAL1
1550 S. Hwy 17 92 Ph: (407) 960-2611
Longwood, FL 32750 Fax: (407) 960-2612
PROPOSAL
12/2/2016 7901
Contractor submits this proposal for work on the property herein described.
Upon acceptance, Contractor agrees to furnish labor and materials necessary
to improve the above premises in a good, workmanlike and substantial
manner according to the terms, specifications, prices and plans (if any).
Start and Completion: The approximate start date:of and
approximate completion date of are subject to permissible
delays as per provision (5) on the reverse side.
Submitted by X
Approved and Accepted (Contractor) Date
Remove existing shingle roofing and underlayment to expose decking. 5,750.00 5,750.00
All damaged plywood decking if any will be determined at completion of tear off and can be replaced at a rate
of $60.00 per 4x8 sheet. (Price includes labor and materials.)
Install 2 1/2in. 8D Rink Shank coil nails along all trusses every six inches to properly secure decking.
Install one layer of Synthetic underlayment over entire roof.
Install 2 1/2in. galvanized eave-drip around entire perimeter of roof. (Save drip will have a baked enamel
finish)
Install New lead boots and vents.
Install 25yr Tamko Elite 3 -tab shingles with a wind resistance of up to 60mph. Shingles will be installed six
nails per shingle.
Ground will be swept with a magnet at the end of each working day.
Clean entire work area and haul away all debris.
2 YEAR LEAK WARRANTY (LABOR AND MATERIALS)
Price includes labor, materials and taxes.
TOTAL $5,750.00
ACCEPTANCE OF PROPOSAL
This Proposal is approved and accepted. There are no oral agreements. The written terms,
specifications, provisions, prices and plans (if any) are the entire agreement. Changes will be X
made by written chance order only. Credit cards may be subiect to a 3% convenience charge. Approved and Accepted(Owner) Date
You, the Buyer, may cancel this transaction at any time prior to midnight of the third business day after the date
of this transaction. See Owner's Right to Cancel on the reverse side for details.
concurrently with the binding dispute resolution but, in such event, mediation shall proceed in advance of binding dispute
resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed
for a longer period by agreement of the parties or court order. if an arbitration is stayed pursuant to this Section, the parties
may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings.
§ 21.4 If the parties have selected arbitration as the method for binding dispute resolution in the Agreement, any claim,
subject to, but not resolved by, mediation shall be subject to arbitration which, unless the parties mutually agree otherwise,
shall be administered by the American Arbitration Association, in accordance with the Construction Industry Arbitration
Rules in effect on the date of this Agreement. Demand for arbitration shall be made in writing, delivered to the other party to
the Contract, and filed with the person or entity administering the arbitration. The award rendered by the arbitrator or
arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having
jurisdiction thereof.
§ 21.5 Either party, at its sole discretion, may consolidate an arbitration conducted under this Agreement with any other
arbitration to which it is party provided that (1) the arbitration agreement governing the other arbitration permits
consolidation; (2) the arbitrations to be consolidated substantially involve common questions of law or fact; and (3) the
arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s).
§ 21.6 Any party to an arbitration may include by joinder persons or entities substantially involved in a common question of
law or fact whose presence is required if complete relief is to be accorded in arbitration provided that the party sought to be
joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute
consent to arbitration of a Claim not described in the written Consent.
§ 21.7 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly
consented to by parties to the Agreement shall be specifically enforceable under applicable law in any court having
jurisdiction thereof.
§ 21.8 Claims for Consequential Damages
The Contractor and Owner waive claims against each other for consequential damages arising out of or relating to this
Contract. This mutual waiver includes.
.1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and
reputation, and for loss of management or employee productivity or of the services of such persons; and
.2 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed
there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising directly
from the Work.
This mutual waiver is applicable, without limitation, to all consequential damages due to either party's termination in
accordance with Article 20. Nothing contained in this Section 21.8 shall be deemed to preclude an award of liquidated
damages, when applicable, in accordance with the requirements of the Contract Documents.
This Agreement entered into as of the day and year first written above.
OWNER (Signature)
(Printed name and title)
CONTRACTOR (Signature)
(Printed name and title)
AIA Document A107"' — 2007. Copyright ®1936, 1951, 1958, 1961, 1963. 1966, 1970, 1974, 1978, 1987, 1997 and 2007 by The American Institute of
(nit. Architects. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or 20
distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum
1 extent possible under the law. This document was created on under the terms of AIA Documents -on -Demand"' order no. and is not for
resale. This document is licensed by The American Institute of Architects for one-time use only, and may not be reproduced prior to Its completion.
Tk;. ie a Den...dn..li— and ie -0 f— —1.
Brian Sikes
OWRG Inc.DATE PROPOSAL
1550 S. Hwy 17 92 Ph: (407) 960-2611
Longwood, FL 32750 Fax: (407) 960-2612
PROPOSAL
12/2/2016 1 7901
Contractor submits this proposal for work on the property herein described.
Upon acceptance, Contractor agrees to furnish labor and materials necessary
to improve the above premises in a good, workmanlike and substantial
manner according to the terms, specifications, prices and plans (if any).
Start and Completion: The approximate start date of and
approximate completion date of are subject to permissible
delays as per provision (5) on the reverse side.
Submitted by X
Remove existing shingle roofing and underlayment to expose decking.
All damaged plywood decking if any will be determined at completion of tear off and can be replaced at a rate
of $60.00 per 4x8 sheet. (Price Includes labor and materials.)
Install 2 1/2in. 8D Rink Shank coil nails along all trusses every six inches to properly secure decking.
Install one layer of Synthetic underlayment over entire roof.
Install 2 1/2in. galvanized eave-drip around entire perimeter of roof. (Save drip will have a baked enamel
finish)
Install New lead boots and vents.
Install 25yr Tamko Elite 3 -tab shingles with a wind resistance of up to 60mph. Shingles will be installed six
nails per shingle.
Ground will be swept with a magnet at the end of each working day.
Clean entire work area and haul away all debris.
2 YEAR LEAK WARRANTY (LABOR AND MATERIALS)
Price includes labor, materials and taxes.
This Proposal is approved and accepted. There are no oral agreements. The written terms,
specifications, provisions, prices and plans (if any) are the entire agreement. Changes will be
be subiect to a 3% convenience
5,750.00 1 5,750.00
TOTAL $5,750.00
_Iz Jz
Date
You, the Buyer, may cancel this transaction at any time prior to midnight of the third business day after the date
of this transaction. See Owner's Right to Cancel on the reverse side for details.
SPECIFIC POWER OF ATTORNEY
I, Yoram Yahav, holder of U.S passport no. 712305896, do hereby appoint Mrs. Denise
McKinley I.D. No. M254-176-62-510-0 of 4524 Old Carriage Trl Oviedo. Fl 32765-
8473, to represent me with respect to the property on 412 S Oak Avenue Sanford FL
32771 ("the property").
I grant Mrs. McKinley the specific power of attorney to sign any document concerning
the roofing of the said property by Brian Sikes roofing
This document shall become effective upon the date of my signature.
Dated this ":� day of December 2016.
Yoram Yahav
Authentication of Amature
I the undersigned, Hagit Kochba, Adv. L.N. 19595 OF Israel Hereby certify that on 7
of December 2016 there appeared before me Mr. Yoram Yahav U.S passport no.
712305896 and signed of his free will this power of attorney.
F. #Is4Kocb�t
90Hacha et or uds
Hagit Kochba, Adv.
Prepared by and return to:
Jeffrey L. Kaplan
Kaplan Law Firm, P.L.
130 Remington Drive Suite 1000
Oviedo, FL 32765
407-706-6700
File Number: 2104-68
Will Call No.:
[Space Above This Line For Recording Data]
Warranty Deed
This Warranty Deed made this 15th day of November, 2016 between Henry E. Clayton, Sr. and Marilyn A.
Clayton, husband and wife whose post office address is 850 Loretta Drive, Titusville, FL 32780, grantor, and Yoram
Yahav, a single man whose post office address is 33 Tabenkin Street, Tel Aviv, 69353, Israel, grantee:
(Whenever used herein the tenns "grantor" and "grantee" include all the patties to this instrument and the heirs, legal representatives, and assigns of
individuals, and the successors and assigns of corporations, trusts and trustees)
Witnesseth, that said grantor, for and in consideration of the sum of TEN AND NO/100 DOLLARS ($10.00) and other
good and valuable considerations to said grantor in hand paid by said grantee, the receipt whereof is hereby acknowledged,
has granted, bargained, and sold to the said grantee, and grantee's heirs and assigns forever, the following described land,
situate, lying and being in Seminole County, Florida to -wit:
UNIT 2, HOMES ON THE PARK, OAK AVENUE, SANFORD, FLORIDA, DESCRIBED AND
DELINEATED ON SURVEY AND PLAT OF HOMES ON THE PARK, RECORDED IN
OFFICIAL RECORDS BOOK 1537, PAGE 325, OF THE PUBLIC RECORDS OF SEMINOLE
COUNTY, FLORIDA.
ALSO DESCRIBED AS: FROM THE NORTHEAST CORNER OF BLOCK 6, TIER 5, E.R.
TRAFFORD'S MAP OF THE TOWN OF SANFORD, ACCORDING TO THE PLAT THEREOF,
AS RECORDED IN PLAT BOOK 1, PAGES 56-64, OF THE PUBLIC RECORDS OF SEMINOLE
COUNTY, FLORIDA, RUN SOUTH ALONG THE EAST LINE OF SAID BLOCK 6, A DISTANCE
OF 150.023 FEET; THENCE RUN WEST 53.083 FEET FOR A POINTOF BEGINNING; THENCE
CONTINUE WEST 37.083 FEET; THENCE RUN SOUTH 46.083 FEET; THENCE RUN EAST
37.083 FEET; 'THENCE RUN NORTH 46.083 FEET'1'O THE POINT OF BEGINNING, BEING A
PART OF LOTS 3 AND 4 OF SAID BLOCK 6.
Parcel Identification Number: 25 -19 -30 -SAG -0605-003A
Together with all the tenements, hereditaments and appurtenances thereto belonging or in anywise appertaining.
To Have and to Hold, the salve in fee simple forever.
And the grantor hereby covenants with said grantee that the grantor is lawfully seized of said land in fee simple; that the
grantor has good right and lawful authority to sell and convey said land; that the grantor hereby fully warrants the title to said
land and will defend the same against the lawful claims of all persons whomsoever; and that said land is free of all
encumbrances, except taxes accruing subsequent to December 31, 2015.
In Witness Whereof, grantor has hercunto set grantor's hand and seal the day and year first above written.
DoubleTimeo
Signed, sealed and delivered in our presence:
s�
Witn- s Name: IN 76
Witness Name: .5L.,,
(Scaly
Henry E. ayton, Sr.
' I)
n10
yn A. y o
State of Florida
County of Seminole
The foregoing instrument was acknowledged before me this day of November, 2016 by Henry E. Clayton, Sr. and
Marilyn A. Clayton, who Uare personally known or [X] have ced a driver's license as identification.
[Notary Seal) Nota is /
AMY B. MACCAGNANO Printed Name: c
My Co AMIssioy u FF2: �z�s
:3,.;,.`, EXPIRES Novarnoor 23. 10 8 My Commission Expires: 114)4)('1Y
:
Warranty Deed - Page 2 DoubleTimem
6/30/2016 Florida Bullding Code Online
F pi er SCIS Home I Log In I User Registration I Hot Topics I Submit surcharge I Stats a Fad I publications I FeC Starr I SCIS Site, rap I Udm I Search I
Busines�>
Product Approval
Prof � ' %' 1 USER: public User
Requ
y�nra� nenttwn Innru > 69WICAian o > Appllcotron aetaa
FL # FL15216-R2
Application Type Revision
Code Version 2014
Application Status Approved
Comments
Archived
Product Manufacturer InterWrap, Inc.
Address/Phone/Email 32923 Mission Way
Mission, NON -US 00000
(551) S74-2939
mtupasOi nterwrap. com
Authorized Signature Eduardo Lozano
elozano@lnterwrap.com
Technical Representative Eduardo Lozano
Address/Phone/Email 32923 Mission Way
Mission, NON -US 00000
(778) 945-2891
elozano@lnterwrop.com
Quality Assurance Representative
Address/Phone/Email
Category Roofing
Subcategory Undedayments
Compliance Method Evaluation Report from a Florida Registered Architect or a Licensed
Florida Professional Engineer
Evaluation Report - Hardcopy Received
Florida Engineer or Architect Name who developed Robert Nleminen
the Evaluation Report
Florida License PE -59166
Quality Assurance Entity Intertek Testing Services NA Inc. - ETL/Warnock Hersey
Quality Assurance Contract Expiration Date 11/17/2016
Validated By John W. Knezevich, PE
-' Validation Checklist - Hardcopy Received
Certificate of Independence
Referenced Standard and Year (of Standard)
Equivalence of Product Standards
Certified By
Sections from the Code
1507.2.3
1507.5.3
1507.8.3
1507.9.3
1507.9.5
httpsl/www.goridabullding.org/pripr app o.aspx7param=wGEVXQwtDgv3yWKJZiORAdhyMSkQGQyljaHhVelOpVSvxwSdCoQ%3da/93d
1/2
6/30/2016
Florida Building Code Ordlrte
71507.8
Product Approval Method
Date Submitted
Date Validated
Date Pending FBC Approval
Date Approved
FLti Model, Number or Name
15216.1 RhlnoRoof Underlayments
Limits of use
Approved for use In HVHZ: No
Approved for use outside HVHZ, Yes
Impact Resistant: N/A
Design Pressure: N/A
Other: See ER Section 5 for Umits of Use.
Method 2 Option B
04/28/2015
04/29/2015
05/04/2015
06/23/2015
Description
Synthetic roof underlayments
Installation Instructions
FLIS216 R2 11 2015 04 FINAL ER INTERWRAP RHINOROOF FL152.16-
S2. od
Verified By: Robert Nleminen PE -59166
Created by Independent Third Party: Yes
Evaluation Reports
FL 5216 R2 AE 201S 04 FINAL ER INTERWRAP RHIN_OROOF FL15216-
Created by Independent Third Party: Yes
p,rcr Ntrt
Contact :: 1940 North Monroe Sheet 7blleheKee FL "— phone: 850.487-1624
The Soto of Florlde Is an AA/EED employer. CoovdaM 2007.2013 State of Florlde.:: Prlyea Statement :; Aceesslblllty StatepLnt :; Refund Shitamepb
Under Florida law, email arkbecses are public records. It you do rmt want your rmoll address released in reslwme to o publrc•recoros request. do not send dectronlc
mad to this entity. Imintid, Cmtxl Out o10M by phone or by tradlllonal mall. 11 you have any gtr¢dtloM„ please crMu 2 850,497..1395. •Ptasuint to Section
455.275(1), Florida Statutcs. eticalvo 0,10ber 1. 2012, licensees ha rued under Omptcr 455, F.S. must provide the Deparmtusnt with on email acklmss It they have
one. The smalls provldms may bd used for ollldal communication vAth the Ileenwu. 14owever enroll addres+es mo pills record. 11 you do not wish to supply a
personal acklm s, please provide ties Oc;partmgm wltlt an email address which can bn made avatlable'to the public. 1D determine of you are a nconseo under Chapter
455• F.S., llel,Se dish bUr•.
Product Approval Amilptat
®®®®
w.rmrit v
hnpaJANww.florldWxAldlrg.org/pr/pr appdtl.espx?peram=wGEVXCtwtDgv3yWKJZ1QRAdhy12u8k000yljaHhVelOpVSvxwSdCoQ%3d%3d ?12
TRINITY ' ERD
EVAWATION REPORT
Interwrap, Inc.
32923 Mission Way
Mission, BC V2V-6E4
Canada
EXTERIOR RESEARCH & DESIGN, I.I.C.
Certificate of Authorization #9503
353 CHRISTIAN STREET, UNIT #13
OXFORD, CT 06478
PHONE: (203) 262-9245
FAX: (203) 262-9243
Evaluation Report 140510.02.12-R2
FLiS216-R2
Date of Issuance: 02/17/2012
Revision 2:04/27/2015
SCOPE:
This Evaluation Report Is issued under Rule 61G20-3 and the applicable rules and regulations governing the use of
construction materials in the State of Florida. The documentation submitted has been reviewed by Robert Nieminen,
P.E. for use of the product under the Florida Building Code and Florida Building Code, Residential Volume. The
products described herein have been evaluated for compliance with the 5th Edition (2014) Florida Building Code
sections noted herein.
DESCRIPTION: RhinoRoof Underlayments
LABELING: Labeling shall be in accordance with the requirements the Accredited Quality Assurance Agency noted
herein.
CONTINUED COMPLIANCE: This Evaluation Report is valid until such time as the named product(s) changes, the referenced
Quality Assurance documentation changes, or provisions of the Code that relate to the product change. Acceptance of
this Evaluation Report by the named client constitutes agreement to notify Robert Nieminen, P.E. if the product
changes or the referenced Quality Assurance documentation changes. Trinityl ERD requires a complete review of this
Evaluation Report relative to updated Code requirements with each Code Cycle.
ADVERTISEMENT: The Evaluation Report number preceded by the words "Trinity IERD Evaluated" may be displayed in
advertising literature. If any portion of the Evaluation Report is displayed, then it shall be done in Its entirety.
INSPECTION: Upon request, a copy of this entire Evaluation Report shall be provided to the user by the manufacturer or
its distributors and shall be available for inspection at the job site at the request of the Building Official.
This Evaluation Report consists of pages 1 through 3.
Prepared by:
Robert J.M. Nieminen, P.E.
Florida Registration No. 59166, Florida DCA ANE1983
'the laatmNe teal ra
appeasb%cat authorlrad by Ilobnrt hlelnbrcrl.
P.ton04/27/2074, 11hisdwsstat tmveasanoleclroNcallyu4nad
docmr ent. Slpnod, scoled hardcoples hove been transmitted to the
Produrt Aplwaval Admbrbtrator and to tho rumM Client
CERTIFICATION OF INDEPENDENCE:
1. Trinity lERD does not have, nor does it intend to acquire or will It acquire, a financial interest in any company manufacturing or
distributing products it evaluates.
2. Trinity lERD is not owned, operated or controlled by any company manufacturing or distributing products it evaluates.
3. Robert Nieminen, P.E. does not have nor will acquire, a financial interest In any company manufacturing or distributing products for
which the evaluation reports are being Issued.
4. Robert Nleminen, P.E. does not have, nor will acquire, a financial interest in any other entity involved in the approval process of the
product.
S. This is a building code evaluation. Neither Trinity lERD nor Robert Nieminen, P.E. are, in any way, the Designer of Record for any
project on which this Evaluation Report, or previous versions thereof, is/was used for permitting or design guidance unless retained
specifically for that purpose.
Agency Code 12-0004-00
Policy Number 122312-20167484
COMMERCIAL GENERAL LIABILITY
55373 (1-07)
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
BLANKET ADDITIONAL INSURED
This endorsement modes insurance provided under the following:
COMMERCIAL GENERAL LIABILITY COVERAGE FORM.
A. Under SECTION II - WHO IS AN INSURED, the
following is added:
A person or organization is an Additional Insured,
only with respect to liability arising out of 'your work"
for that Additional Insured by or for you:
1. If required in a written contract or agreement: or
2. If required by an oral contract or agreement only
if a Certificate of Insurance was issued prior to
the loss indicating that the person or organiza-
tion was an Additional Insured.
B. Under SECTION III - LIMITS OF INSURANCE, the
following is added:
The limits of liability for the Additional Insured are
those specified in the written contract or agreement
between the insured and the owner, lessee or
contractor or those specked in the Certificate of
Insurance, if an oral contract or agreement, not to
exceed the limits provided in this policy. These
limits are inclusive of and not in addition to the limits
of insurance shown in the Declarations.
C. SECTION IV - COMMERCIAL GENERAL
LIABILITY CONDITIONS, is amended as follows:
1. The following provision is added to 4. Other
Insurance:
This insurance is primary for the Additional
Insured, but only with respect to liability arising
out of "your work" for that Additional Insured by
or for you. Other insurance available to the
Additional Insured will apply as excess insur-
ance and not contribute as primary insurance to
the insurance provided by this endorsement.
2. The following provision is added:
Other Additional Insured Coverage Issued By
Us
If this policy provides coverage for the same
loss to any Additional Insured specifically shown
as an Additional Insured in another endorsement
to this policy, our maximum limit of insurance
under this endorsement and any other endorse-
ment shall not exceed the limit of insurance in
the written contract or agreement between the
insured and the owner, lessee or contractor, or
the limits provided in this policy, whichever is
less. Our maximum limit of insurance arising
out of an "occurrence", shall not exceed the limit
of insurance shown in the Declarations, regard-
less of the number of insureds or Additional
Insureds.
All other policy terms and conditions apply.
Includes copyrighted material of Insurance Services Office, Inc., with its permission.
55373 (1-07) Copyright Insurance Services Office, Inc., 1984.2003. Page 1 of 1
THIS INSTRUMENT PREPARED BY:
Name: Saundra Rosberg '
Address: 1550 S Hwy 17 92
Longwood, FI 32750
NOTICE OF COMMENCEMENT
Permit Number.
Parcel ID Number. 25-19-30-5AG-0605-003A
111111111111 lllil lllil lilll 11111 1111 1111
MARYANNE MORSE, SE11INOLE COUNTY
CLERIC OF CIRCUIT COURT & COMPTROLLER
BY. 8823 P9 760 (iP9s)
CLERK'S T 2016128857
RECORDED 12/13/2016 10:21:42 All
RECORDING FEES $111.00
RECORDED BY hdevot-e
The undersigned hereby gives notice that improvement will be made to certain real property, and In accordance with Chapter 713, Florida Statutes, the
following information is provided in this Notice of Commencement.
1. DESCRIPTION OF PROPERTY: (Legal description of the property and street address if available)
COR BLK 6 TR 5 RUN W 37.083 FT 412 S. Oak Avenue Sanford, FI 32771
2. GENERAL DESCRIPTION OF IMPROVEMENT:
Re -Roof Tamko Elite 3 -tab Shingles 25sq
3. OWNER INFORMATION OR LESSEE INFORMATION IF THE LESSEE CONTRACTED FOR THE IMPROVEMENT:
Name and address: Yoram Yahav 412 S. Oak Avenue Sanford, FI 32771
Interest In property: Owner
Fee Simple Title Holder (If other than owner listed above) Name:
Address:
4. CONTRACTOR: Name: Brian Sikes Phone Number. 407-878-3750
Address: 1550 S Hwy 17 92 Longwood, FI 32750
6. SURETY (If applicable, a copy of the payment bond is attached): Name:
Address: Amount of Bond:
6. LENDER: Name: Phone Number:
Address:
7. Persons within the State of Florida Designated by Owner upon whom notice or other documents maybe served as provided by Section
713.13(1)(a)7., Florida Statutes.
Name: Phone Number:
Address:
8. In addition, Owner designates
of
to receive a copy of the Lienors Notice as provided In Section 713.13(1)(b), Florida Statutes. Phone number:
9. Expiration Dale of Notice of Commencement (The expiration Is 1 year from date of recording unless a different date Is specified)
WARNING TO OWNER: ANY PAYMENTS MADE BY THE OWNER AFTER THE EXPIRATION OF THE NOTICE OF COMMENCEMENT ARE
CONSIDERED IMPROPER PAYMENTS UNDER CHAPTER 713, PART I, SECTION 713.13, FLORIDA STATUTES, AND CAN RESULT IN YOUR
PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE
JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY
BEFORE COMMENCING WORK OR RECORDING YOUR NOTICE OF COMMENCEMENT.
(51WW M of Owner or lessee. or 0"N'e or Lessee'e (Print Nano and Provido Slpnetory'a Tido/Omce)
Authodzed 016cerOmdor/Partner/Mmep 4 ly
State of� County of
The foregoing Instrument was acknowledged before me this day of 4
by %i La J�j Who is personally known tom OR
who has produced Identification O type of Identification produced:
DINELIA I. COMINSKY
*MY COMMISSION / FF 064147 .
EXPIRES: February 18,2D18 Q:ERTiFtEo
it"to�"*6v4sd Thru8vdret NourySerlttt
BE 13 2016
IYANNC MUK�C "
COURT AND •'
stun
BY //V DEPUTY CLERK
CITY OF SANFORD BUILDING SERVICES
Residential Re -Roof
Hurricane Mitigation Inspection Affidavit
Permit #: Ili- 2)5;;3
I, hereby acknowledge that I personally inspected
Roof deck nailin&r jnSecondary water barrier work
at
and have determined that the work
(Job Site Address)
was done according to the Hurricane Mitigation Retrofit Manual. (based on 553.844 F.S.)
I certify that my statements herein are true and accurate to the best of my belief and that I fully
understand that making any false statements in writing with the intent to mislead a public servant in the
performance of his or her official duty shall constitute a misdemeanor of the second degree pursuant to
Section 837.06 F.S.
Signature of Contractor Date
Printed Name of Cont ctor License #
License Type: 0 General 0 Building 0 Residential XRoofing Contractor
0 or any individual certified in accordance with F.S. 468 to make such an inspection.
STATE OF FLORIDA COUNTY OF��h�/� �_ /
Sworn to (or affirmed) and subscribed before me this day of fj , 20 , by
who io--e,.Personally Known to me or has 0 Produced (type of
5znMature::
as identification.
(SEAL)
ry Public
State of Florida
LII 0Com/ W � Notary Public Stats of Florida
16— Steven Campbell
Print/Type/Stamp Name My commiaror, FF 990959
of Notary Public �+a Expires 05/10/2020