Loading...
HomeMy WebLinkAbout2658 IFB 25/26-09 Sanford PWC CHiller Replacement - (payment & perf bonds)IInn CITY OF SANFORD FINANCE DEPARTMENT Tuesday, March 03, 2026 PURCHASING DEPARTMENT TRANSMITTAL MEMORANDUM To: City Clerk/Mayor RE: IFB 25/26-09 Sanford PSC Chiller Replacement - P&P Bonds The item(s) noted below is/are attached and forwarded to your office for the following action(s): ❑ Development Order ❑ Mayor's signature ❑ Final Plat (original mylars) ❑ Recording ❑ Letter of Credit ❑ Rendering ❑ Maintenance Bond ❑ Safe keeping (Vault) ❑ Ordinance ❑ Deputy City Manager ® Performance Bond ® Payment Bond ❑ Resolution ❑ City Manager Signature ❑ ❑ City Clerk Attest/Signature ❑ City Attorney/Signature Once completed, please: ® Return originals to Purchasing- Department ❑ Return copies Special Instructions: IFB 25/26-09 Sanford PSC Chiller Replacement - P&P Bonds for filing Robe rt- Ri Oo From T:\Dept_forms\City Clerk Transmittal Memo - 2009.doc 3/3/2026 Date BOND # 7901286925 IPAIA D m n r"-1 ocu et A 3122 00 W� 0_. o� Z O Performance Bond Cn v ,y CONTRACTOR: SURETY: CD (Name, legal status and address) (Name, legal status and principal ni c ENFRA MCC, LLC place of business) n 1151 N Keller Rd. Nationwide Mutual Insurance Company O Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR a in Columbus, OH 43215-2220 -n IF 7 OWNER: This document has important r CA) p (Name, legal status and address) legal consequences. to V <. The City of Sanford, Florida, a Municipality Consultation with an attorney v rn 300 Park Avenue is encouraged with respect to O Sanford, FL 32771-1788 its completion or modification. p CONSTRUCTION CONTRACT Any singular reference to Date: Contractor, Surety, Owner or other party shall be considered Amount $103,889.00 plural where applicable. Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPH Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 Modifications to this Bond: 0 None See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company (Corporate ENFRA MCC, LLC Nationwide Mutual Insu anc Signature: Signature: Name and Name an Tawanda A. W th Title: Title: Attorney -in -Facts (Any additional signatures appear on the last page of this Performance Bon (FOR INFORMATION ONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Arthur J Gallagher Risk Management (Architect; Engineer or other party.) Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 AIA Document A312TI — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA" Document Is protected Init. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA' Document, or anv Portion of It. may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A312TM — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA" Document Is protected Init. by U.S. Copyright Law and Intemational'rreaties. Unauthorized reproduction or distribution of this AIAa Document, or any portion of it, may result In 2 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. AIA Document A3121" — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA® Document Is protected [nit. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any pa Mon of It, may result In 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company (Corporate Seal) Company. (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: Init. AIA DocumentA312TO — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA° Document Is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA`' Document, or any portion of it, may result In 4 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: BOND # 7901286925 St. .�®TM Document A312 2010 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal ENFRA MCC. LLC place of business) 1151 N Keller Rd. Nationwide Mutual Insurance Company Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR Columbus, OH 43215-2220 OWNER: (Name, legal status and address) The City of Sanford, Florida, a Municipality 300 Park Avenue Sanford, FL 32771-1788 CONSTRUCTION CONTRACT Date: Amount $103,889.00 Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPH Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 Modifications to ttus Bond: 0 None See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company, (Corpor to ENFRA MCC, LLC Nation ide Mutual Insur ci Signature: Signor Name and Name and Tiwanda A. Ve411 Title: Title: Attorney-i et (Any additional signatures appear on the last page f this Pay nt Bo d (FOR INFORMATION ONLY— Name, address and telep one) AGENT or BROKER: OWNER'S REPRESENTATIVE: Arthur J Gallagher Risk (Architect Engi er or Management Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA` Document Is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this Ale Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment famished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last fin-nished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor famishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Document A312- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA' Document Is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of It, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly fixrnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment fiunished as of the date of the Clain; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A312- - 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This Alk1g Document is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAM Document, or any portion of It, may result in 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA Document A312- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAO Document Is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this Ate Document, or any portion of It, may result In 4 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: Power of Attorney Bond Number: KNOW ALL MEN BY THESE PRESENTS THAT: Nationwide Mutual Insurance Company, an Ohio corporation hereinafter referred to severally as the "Company" and collectively as "the Companies" does hereby make, constitute and appoint: AMY L DOUGAY; CHARLES E REAGIN, III; CHARLOTTE RAMSEY; CHARLOTTE L WRIGHT; CHRISTOPHER BOONE; DAVID FORTENBERRY; DEBBIE L DUNAWAY; DEWEY MASON; JENNIFER S ROBERTS; JOSEPH BEATTIE; JULEE C LIVINGSTON, KATHLEEN SCARBOROUGH; KIMBERLY BARHUM; LISA BUTLER; MARKHAM R MCKNIGHT; MARY E KLEINPETER; PATRICK MASON; ROXANNA S BORER; STEPHANIE S MCKNIGHT; STEVEN P THIBODEAUX; SUSAN SKRIAETTA; TAWANDA A WEATHERSPOON; THOMAS M SANDAHL; TRENT J SANDAHL; TROY WAGENER; WILLIAM G MCKNIGHT; each in their individual capacity, its true and lawful attomey-in-fact, with full power and authority to sign, seal, and execute on its behalf on the date thereof any and all: (i)bonds and undertakings; (ii) Proposal Bonds; (ii) Letters of Surety; (iv) Consent of Surety; and (v) other obligatory instruments of similar nature, in penalties not exceeding the sum of UNLIMITED and to bind the Company thereby, as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Company; and all acts of said Attorney pursuant to the authority given are hereby ratified and confirmed. This power of attorney is made and executed pursuant to and by authority of the following resolution duty adopted by the board of directors of the Company: "RESOLVED, that the president, or any vice president be, and each hereby is, authorized and empowered to appoint attomeys-in-fact of the Company, and to authorize them to execute and deliver on behalf of the Company any and all bonds, forms, applications, memorandums, undertakings, recognizances, transfers, contracts of indemnity, policies, contracts guaranteeing the fidelity of persons holding positions of public or private trust, and other writings obligatory in nature that the business of the Company may require; and to modify or revoke, with or without cause, any such appointment or authority; provided, however, that the authority granted hereby shall in no way limit the authority of other duly authorized agents to sign and countersign any of said documents on behalf of the Company." "RESOLVED FURTHER, that such attomeys-in-fact shall have full power and authority to execute and deliver any and all such documents and to bind the Company subject to the terms and limitations of the power of attorney issued to them, and to affix the seal of the Company thereto; provided, however, that said seal shall not be necessary for the validity of any such documents." This power of attorney is signed and sealed under and by the following bylaws duly adopted by the board of directors of the Company. Execution of Instruments. Any vice president, any assistant secretary or any assistant treasurer shall have the power and authority to sign or attest all approved documents, instruments, contracts, or other papers in connection with the operation of the business of the company in addition to the chairman of the board, the chief executive officer, president, treasurer or secretary; provided, however, the signature of any of them may be printed, engraved, or stamped on any approved document, contract, instrument, or other papers of the Company. IN WITNESS WHEREOF, the Company has caused this instrument to be sealed and duly attested by the signature of its officer the 23rd day of October, 2025. Antonio C. Albanese, Vice President of Nationwide Mutual Insurance Company ACKNOWLEDGMENT STATE OF OHIO COUNTY OF FRANKLIN: ss 'XA� On this 23rd day of October, 2025, before me came the above -named officer for the Company to me known to be the officer described in and who executed aforesaid, personally ithe preceding instrument, and he acknowledged the execution of the same, and being by me seer�aa duly sworn, deposes and says, that he is the officer of the Company aforesaid, that the seal ` / ............ affixed hereto is the corporate seal of said Company, and the said corporate seal and his signature were duly affixed and subscribed to said instrument by the authority and direction of said Company. Karen L. Kam Notary Public, State of Ohio No. 2018-RE-719796 Notary Pub& Commission Expires July 7, 2028 My corn July 7. 20 Fiplro P }Y Juy �, 2028 CERTIFICATE I, Lezlie F. Chimienti, Assistant Secretary of the Company, do hereby certify that the foregoing is a full, true and correct copy of the original power of attorney issued by the Company; that the resolution included therein is a true and correct transcript from the minutes of the meetings of the boards of directors and the same has not been revoked or amended in any manner, that said Antonio C. Albanese was on the date of the execution of the foregoing power of attorney the duly elected officer of the Company, and the corporate seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority of said board of directors; and the foregoing power of attorney is still in full force and effect. IN WITNESS WHEREOF, I have hereunto subscribed my name as Assistant Secretary, and affixed the corporate seal of said Company this-�..day of Assistant Secretary BDJ 1(10-25)00 BOND # 7901286925 TM ® . Document A312 - 2010 Performance Bond w() o Z 0 CONTRACTOR: SURETY: cn (Name, legal status and address) (Name, legal status and principal o ENFRA MCC, LLC place of business) m Q 1151 N Keller Rd. Nationwide Mutual Insurance Company Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR v Columbus, OH 43215-2220 0 OWNER: This document has important p 3 (Name, legal status and address) legal consequences. d The City of Sanford, Florida, a Municipality Consultation with an attorney -n O'Q 300 Park Avenue is encouraged with respect to N Sanford, FL 32771-1788 its completion or modification, CONSTRUCTION CONTRACT My singular reference to v 1-4rn � _, Date: Contractor, Surety, Owner or O ' other party shall be considered Amount S103,889.00 plural where applicable. Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPU Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 �, Modifications to this Bond: I� None See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company. (� ENFRA MCC, LLC NationwrdeMutuld Signature: j Signature: 'Ic Name and Name and ; Tawanda Title: Title: // Attorney - (Any additional signatures appear on the last page bf this Pe)jFn (FOR XFORMA770NONLY —Name, address and telephone) AGENT or BROKER: OWNER'S REP SENTATIV : (Architect, Engineer or er party.) Arthur J Gallagher Risk Management ' Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 AIA Document A312- — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA° Document Is protected [nit. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this A10 Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself; through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A912- — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected Init. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAe Document, or any portion of it, may result In 2 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. 19 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. AIA Document A31211 - 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA' Document is protected Init. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this Alk' Document, or any portion of it, may result In 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company (Corporate Seal) Company. (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA Document A312TI - 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAI Document Is protected (nit. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA' Document, or any portion of It, may result In 4 severe civil and criminal penatties, and will be prosecuted to the maximum extent possible under the law. User Notes: BOND # 7901286925 .-iAIAD m n A 12TM - 2 1 ocu et 3 00 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal ENFRA MCC, LLC place of business) 1151 N Keller Rd. Nationwide Mutual Insurance Company Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR Columbus, OH 43215-2220 OWNER: (Name, legal status and address) The City of Sanford, Florida, a Municipality 300 Park Avenue Sanford, FL 32771-1788 CONSTRUCTION CONTRACT Date: Amount $103,889.00 Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPH Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 Modifications to this .Bond: None See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company (Corporate Seal) Company,--- (Corpor a Seal) ENFRA MCC, LLC Natrtur wide Mutual Insur a Company Signature: Signe: —� Name and Name and,Tawanda atherspoon Title: Title: / Attorne,bb'=in +a (Any additional signatures appear on the last pagf of this Po ment of I (FOR INFORMA77ONONLY—Name, address and tele hone) AGENT or BROKER: OWNER'S REP ESENT NE: Arthur J Gallagher Risk (Architect, Engineer or other party) Management Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A912- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAe Document Is protected by Irtit. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this Ale Document, a any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last fuu-nished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Document A912- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA°' Document Is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAa Document, or any portion of tt, may result In 2 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last finished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to firnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A312'I - 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA- Document is protected by Init. U.S. Copyright Law and Intemational Treaties. Unauthorized reproduction or distribution of this AW Document, or any portion of It, may result in 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA Document A312- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA"Document Is protected by Init. U.S. Copyright Law and International Treaties. unauthorized reproduction or distribution of this AM" Document, or any portion of I% may result In 4 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: Power of Attorney Bond Number: KNOW ALL MEN BY THESE PRESENTS THAT: Nationwide Mutual Insurance Company, an Ohio corporation hereinafter referred to severally as the "Company" and collectively as "the Companies" does hereby make, constitute and appoint: AMY L DOUGAY; CHARLES E REAGIN, III; CHARLOTTE RAMSEY; CHARLOTTE L WRIGHT; CHRISTOPHER BOONE; DAVID FORTENBERRY; DEBBIE L DUNAWAY; DEWEY MASON; JENNIFER S ROBERTS; JOSEPH BEATTIE; JULIE C LIVINGSTON; KATHLEEN SCARBOROUGH; KIMBERLY BARHUM; LISA BUTLER; MARKHAM R MCKNIGHT; MARY E KLEINPETER; PATRICK MASON; ROXANNA S BORER; STEPHANIE S MCKNIGHT; STEVEN P THIBODEAUX; SUSAN SKRMETTA; TAWANDA A WEATHERSPOON; THOMAS M SANDAHL; TRENT J SANDAHL; TROY WAGENER, WILLIAM G MCKNIGHT; each in their individual capacity, its true and lawful attomey-in-fact, with full power and authority to sign, seal, and execute on its behalf on the date thereof any and all: (i)bonds and undertakings; (ii) Proposal Bonds; (ii) Letters of Surety; (iv) Consent of Surety; and (v) other obligatory instruments of similar nature, in penalties not exceeding the sum of UNLIMITED and to bind the Company thereby, as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Company; and all acts of said Attorney pursuant to the authority given are hereby ratified and confirmed. This power of attorney is made and executed pursuant to and by authority of the following resolution duly adopted by the board of directors of the Company: "RESOLVED, that the president, or any vice president be, and each hereby is, authorized and empowered to appoint attorneys -in -fact of the Company, and to authorize them to execute and deliver on behalf of the Company any and all bonds, forms, applications, memorandums, undertakings, recognizances, transfers, contracts of indemnity, policies, contracts guaranteeing the fidelity of persons holding positions of public or private trust, and other writings obligatory in nature that the business of the Company may require; and to modify or revoke, with or without cause, any such appointment or authority; provided, however, that the authority granted hereby shall in no way limit the authority of other duly authorized agents to sign and countersign any of said documents on behalf of the Company." "RESOLVED FURTHER, that such attomeys-in-fact shall have full power and authority to execute and deliver any and all such documents and to bind the Company subject to the terms and limitations of the power of attorney issued to them, and to affix the seal of the Company thereto; provided, however, that said seal shall not be necessary for the validity of any such documents." This power of attorney is signed and sealed under and by the following bylaws duly adopted by the board of directors of the Company. Execution of Instruments. Any vice president, any assistant secretary or any assistant treasurer shall have the power and authority to sign or attest all approved documents, instruments, contracts, or other papers in connection with the operation of the business of the company in addition to the chairman of the board, the chief executive officer, president, treasurer or secretary; provided, however, the signature of any of them may be printed, engraved, or stamped on any approved document, contract, instrument, or other papers of the Company. IN WITNESS WHEREOF, the Company has caused this instrument to be sealed and duly attested by the signature of its officer the 23rd day of October, 2025. Al-0-- Antonio C. Albanese, Vice President of Nationwide Mutual Insurance Company ACKNOWLEDGMENT 4'_`` ��.. STATE OF OHIO COUNTY OF FRANKLIN: ss '��,. ••�, On this 23rd day of October, 2025, before me came the above -named officer for the ' ' Company aforesaid, to me personally known to be the officer described in and who executed the preceding instrument, and he acknowledged the execution of the same, and being by me 4!t'TU¢plT duly swom, deposes and says, that he is the officer of the Company aforesaid, that the seal ,,;=♦I affixed hereto is the corporate seal of said Company, and the said corporate seal and his signature were duly affixed and subscribed to said instrument by the authority and direction of said Company. — Karen L. Kam Notary Public, State of Ohio No. 2018-RE-719796 Nobry Pubk My Commiuian EYplra Commission Expires July 7, 2028 July 7, 2028 CERTIFICATE I, Lezlie F. Chimienti, Assistant Secretary of the Company, do hereby certify that the foregoing is a full, true and correct copy of the original power of attorney issued by the Company; that the resolution included therein is a true and correct transcript from the minutes of the meetings of the boards of directors and the same has not been revoked or amended in any manner; that said Antonio C. Albanese was on the date of the execution of the foregoing power of attorney the duly elected officer of the Company, and the corporate seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority of said board of directors; and the foregoing power of attorney is still in full force and effect. IN WITNESS WHEREOF, I have hereunto subscribed my name as Assistant Secretary, and affixed the corporate seal of said Company this day of _ Assistant Secretary BDJ 1(10-25)00 e� BOND # 7901286925 AIADocument ocu ent 3 010 Performance Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal ENFRA MCC, LLC place of business) 1151 N Keller Rd. Nationwide Mutual Insurance Company Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR Columbus, OH 43215-2220 OWNER: (Name, legal status and address) The City of Sanford, Florida, a Municipality 300 Park Avenue Sanford, FL 32771-1788 CONSTRUCTION CONTRACT Date: Amount $103,889.00 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPH Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 Modifications to this Bond: 0 None See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company. (Corp ENFRA MCC, LLC Nationwide Mutual In Signature: Signature Name and / Name afid Tawanda es Title: Title Attor -i Fact (Any additional signatures appear on the last page of this,,W"rforma ce B, (FOR INFORMATIONONLY— Name, address and t lephone) AGENT or BROKER: OWNER'S R RESENTAT E: (Architec4 Eng other party:) Arthur J Gallagher Risk Management Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 AIA Document A912- — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING. This AIAO Document is protected Init. by U.S. Copyright Law and Intemational Treaties. Unauthorized reproduction or distribution of this Ale Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. Wl7 o'< Zo User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself; through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A912" — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA" Document Is protected Init. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA, Document, or any portion of it, may result In 2 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or ncn-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. AIA Document A312- — 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected (nit. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AWW' Document, or any portion of It, may result In 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 16 Modifications to this band are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company (Corporate Seal) Company. (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: At Document A312T1 - 2010 Performance Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA3" Document is protected Init. by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA" Document, or any portion of it, may result In 4 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: BOND # 7901286925 MAIA Document A312 TM - 2010 Payment Bond CONTRACTOR: SURETY: (Name, legal status and address) (Name, legal status and principal ENFRA MCC, LLC place of business) 1151 N Keller Rd. Nationwide Mutual Insurance Company Orlando, FL 32810 One West Nationwide Blvd., FSSC-RR Columbus, OH 43215-2220 OWNER: (Name, legal status and address) The City of Sanford, Florida, a Municipality 300 Park Avenue Sanford, FL 32771-1788 CONSTRUCTION CONTRACT Date: Amount $103,889.00 Description: (Name and location) Sanford Public Safety Building Chiller (PSC) Replacement, IFB No. 25/26-09, CPH Job No. 201.2500223 BOND Date: (Not earlier than Construction Contract Date) Amount $103,889.00 Modifications to ttus Bond: None See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company. ENFRA MCC, LLC Nationwid�l Signature: Signature: /q:�: Name and Name and Title: Title: At1 (Any additional signatures appear on the last page of this (FOR INFORMATION OM,Y — Name, address and AGENT or BROKER: OWNER'S 1 Arthur J Gallagher Risk (Architect, Management Services, LLC 4041 Essen Lane, Suite 400 Baton Rouge, LA 70809 utual Insurdhc" anda A. a ers rney-in- ct aym nd 7ne) SENTAT ter or of r party:) This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A912- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA? Document Is protected by [nit. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA? Document, or any portion of It, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment fuunished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Document A312"' - 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA" Document Is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIAa Document, or any portion of I% may result In 2 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been famished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A3121 — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIA`g Document Is protected by [nit. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result In 3 severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company. (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: Signature: Name and Title: Address: AIA Document A912- — 2010 Payment Bond. The American Institute of Architects. All rights reserved. WARNING: This AIAe Document is protected by Init. U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA° Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. User Notes: Power of Attorney Bond Number: KNOW ALL MEN BY THESE PRESENTS THAT: Nationwide Mutual Insurance Company, an Ohio corporation hereinafter referred to severally as the "Company" and collectively as "the Companies" does hereby make, constitute and appoint: AMY L DOUGAY; CHARLES E REAGIN, III; CHARLOTTE RAMSEY; CHARLOTTE L WRIGHT; CHRISTOPHER BOONE; DAVID FORTENBERRY; DEBBIE L DUNAWAY,- DEWEY MASON; JENNIFER S ROBERTS; JOSEPH BEATTIE; JULIE C LIVINGSTON; KATHLEEN SCARBOROUGH; K1 vIBERLY BARHUM; LISA BUTLER; MARKHAM R MCKNIGHT; MARY E KLEINPETER; PATRICK MASON; ROXANNA S BORER; STEPHANIE S MCKNIGHT; STEVEN P THIBODEAUX; SUSAN SKRMETTA; TAWANDA A WEATHERSPOON; THOMAS M SANDAHL; TRENT J SANDAHL; TROY WAGENER; WILLIAM G MCKNIGHT; each in their individual capacity, its true and lawful attomey-in-fact, with full power and authority to sign, seal, and execute on its behalf on the date thereof any and all: (0bonds and undertakings; (J) Proposal Bonds; (ii) Letters of Surety; (iv) Consent of Surety; and (v) other obligatory instruments of similar nature, in penalties not exceeding the sum of UNLIMITED and to bind the Company thereby, as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Company; and all acts of said Attorney pursuant to the authority given are hereby ratified and confirmed. This power of attorney is made and executed pursuant to and by authority of the following resolution duly adopted by the board of directors of the Company: "RESOLVED, that the president, or any vice president be, and each hereby is, authorized and empowered to appoint attorneys -in -fact of the Company, and to authorize them to execute and deliver on behalf of the Company any and all bonds, forms, applications, memorandums, undertakings, recognizances, transfers, contracts of indemnity, policies, contracts guaranteeing the fidelity of persons holding positions of public or private trust, and other writings obligatory in nature that the business of the Company may require; and to modify or revoke, with or without cause, any such appointment or authority; provided, however, that the authority granted hereby shall in no way limit the authority of other duly authorized agents to sign and countersign any of said documents on behalf of the Company." "RESOLVED FURTHER, that such attomeys-in-fact shall have full power and authority to execute and deliver any and all such documents and to bind the Company subject to the terms and limitations of the power of attorney issued to them, and to affix the seal of the Company thereto; provided, however, that said seal shall not be necessary for the validity of any such documents." This power of attorney is signed and sealed under and by the following bylaws duly adopted by the board of directors of the Company. Execution of Instruments. Any vice president, any assistant secretary or any assistant treasurer shall have the power and authority to sign or attest all approved documents, instruments, contracts, or other papers in connection with the operation of the business of the company in addition to the chairman of the board, the chief executive officer, president, treasurer or secretary; provided, however, the signature of any of them may be printed, engraved, or stamped on any approved document, contract, instrument, or other papers of the Company. IN WITNESS WHEREOF, the Company has caused this instrument to be sealed and duly attested by the signature of its officer the 23rd day of October, 2025. Alo__ Antonio C. Albanese, Vice President of Nationwide Mutual Insurance Company ACKNOWLEDGMENT STATE OF OHIO COUNTY OF FRANKLIN: ss Aro�N�tixsu� On this 23rd day of October, 2025, before me came the above -named officer for the IF Company aforesaid, to me personally known to be the officer described in and who executed *SEAL ;#, the preceding instrument, and he acknowledged the execution of the same, and being by me r,duty '•.. s;rugarr AF swom, deposes and says, that he is the officer of the Company aforesaid, that the seal affixed hereto is the corporate seal of said Company, and the said corporate seal and his =�I signature were duly affixed and subscribed to said instrument by the authority and direction of said Company. Karen L. Kam" Notary Public, State of Ohio No. 201"E-719796 Nomry .. E Commission Tres July 7, 2028 My Corn July 7. 20 E:pict �P' IY ,wy �. zoze CERTIFICATE I, Lezlie F. Chimienti, Assistant Secretary of the Company, do hereby certify that the foregoing is a full, true and correct copy of the original power of attorney issued by the Company; that the resolution included therein is a true and correct transcript from the minutes of the meetings of the boards of directors and the same has not been revoked or amended in any manner, that said Antonio C. Albanese was on the date of the execution of the foregoing power of attorney the duly elected officer of the Company, and the corporate seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority of said board of directors; and the foregoing power of attorney is still in full force and effect. IN WITNESS WHEREOF, I have hereunto subscribed my name as Assistant Secretary, and affixed the corporate seal of said Company this day of c oa�� f 6,5L_M1 Assistant Secretary BDJ 1(10-25)00