Loading...
1029-Gomez Construction Co 1stSECTION 00520 Co N— / . D— ,-/ AGREEMENTFORM PART 1 GENERAL 1.01 THIS AGREEMENT, made this 22nd day of July 2004 by and between 1) The the Owner, and 2) Gomez Construction Company and hereinafter called the Contractor. 1) Name of Owner 2) Name o / Contractor 3) Corporation, Partnership, Sole Proprietor 1.02 The Owner and Contractor agree as follows: A. Contract Documents Agency (CRA) hereinafter called doing business as a 3) Corporation The Contract Documents include the Agreement, Addenda (which pertain to the Contract Documents), Contractor's Bid, Notice to Proceed, the Bonds, the General Conditions, the Supplementary Conditions, the Specifications listed in the Index to the Project Manual, any technical specifications as incorporated by the Project Manual; the Drawings as listed in the Project Manual, all Written Amendments, Change Orders, Work Change Directives, Field Orders, and Engineer's written interpretations and Clarifications issued on or after the Effective Date of this Agreement. These form the Contract and all are as fully a part of the Contract as if attached to this Agreement or repeated herein. B. Scope of Work The Contractor shall perform all work required by the Contract Documents for the construction of the 4) Historic First Street Streetscape Project 4) Name of Proiect identified in Invitation for Bids C. Contract Time The Contractor shall begin work within 10 days after the issuance of a written Notice to Proceed and shall substantially complete the work no later than December 31, 2004 The work shall be finally complete, ready for Final Payment in accordance with the General Conditions, within 30 calendar days from the actual date of substantial completion. 5) As specified in paragraph 1.02/C/5 of the Bid Form D. Incentive /Disincentive OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not SPECUB021104 00520 -1 u.. C9 N v cr cv NAME OF PROJECT: First Streetscape Project. Sanford. Florida substantially complete within the time specified in Paragraph C above, plus any extensions thereof allowed in accordance with the General Conditions. They also recognize the delays, expense and difficulties involved in proving in a legal arbitration proceeding the actual loss suffered by OWNER if the Work is not substantially complete on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR hereby agree to the incentive — disincentive provision described below. The City desires to expedite construction on this Contract to minimize the inconvenience to the traveling public and to reduce the time of construction. In order to achieve this, an incentive - disincentive provision is established for the Contract. The total incentive payment shall not exceed $ 50.000 In the event the Contractor substantially completes the Contract prior to December 31, 2004, the City will pay the Contractor an incentive payment in the amount of $ 1,500 for each calendar day the actual substantial completion date precedes this date subject to the conditions set forth below. The term "calendar day" as used in this Article will mean every day shown on the calendar. The term "substantial completion" as used in this Article will mean the date the entire project area is ready to be used for its intended use. (See 00700 Article 1.01 Item 45) If a few incidental items such as landscaping, irrigation, bike racks, benches etc. are in the final stages of completion the City of Sanford may approve the project for substantial completion with an agreed upon check list to be completed within 30 calendar days. For purposes of the calculation and the determination of the "incentive payment' stated above, this date will not be adjusted for any reason, cause or circumstance whatsoever, regardless of fault, save and except in the instance of a catastrophic event (i.e., hurricane or a declared state of emergency). The parties anticipate that delays may be caused by or arise from any number of events during the course of the Contract, including, but not limited to, work performed, work deleted, change orders, supplemental agreements, delays, disruptions, differing site conditions, utility conflicts, design changes or defects, time extensions, extra work, right of way issues, permitting issues, actions of suppliers, subcontractors or other contractors, actions by third parties, shop drawing approval process delays, expansion of the physical limits of the project to make it functional, weather, weekends, holidays, suspensions of Contractor's operations, or other such events, forces or factors sometimes experienced in roadway construction work. Such delays or events and their potential impacts on performance by the Contractor are specifically contemplated and acknowledged by the parties in entering into this Contract, and shall not extend the date set for purposes of calculation of the "incentive payment' set forth above. Further, any and all costs or impacts whatsoever incurred by the Contractor in accelerating the Contractor's work to overcome or absorb such delays or events in an effort to complete the Contract prior to this date regardless of whether the Contractor successfully does so or not, shall be the sole responsibility of the Contractor in every instance. SPECLIS021104 00520 -2 NAME OF PROJECT: First Streetscaoe Project, Sanford. Florida In the event of a catastrophic event (i.e., hurricane or a declared state of emergency) directly and substantially affecting the Contractor's operations on the Contract, the Contractor and the City shall agree as to the number of calendar days to extend the substantial completion date so that such extended date will be used in calculation of the "incentive payment". In the event the Contractor and City are unable to agree to the number of calendar days to extend the date of substantial completion, the City shall unilaterally determine the number of calendar days to extend the date of substantial completion reasonably necessary and due solely to such catastrophic event and the Contractor hereby waives all rights, if any, whatsoever to contest such determination. The Contractor shall have no rights under the Contract to make any claim arising out of this "incentive payment' provision. Should the Contractor fail to substantially complete the Contract on or before December 31, 2004 the City shall deduct from the monies due the Contractor $1,500 for each calendar day substantial completion exceeds this date. This deduction shall be the disincentive for the Contractor's failing to timely complete the Contract and shall be deducted, not as a penalty, but as liquidated damages. Any and all costs or impacts whatsoever incurred by the Contractor in accelerating the Contractor's work to overcome or absorb such delays or events in an effort to complete the Contract prior to this date regardless of whether the Contractor successfully does so or not, shall be the sole responsibility of the Contractor in every instance. E. Contract Price Unit Price Contract The Owner will pay the Contractor in current funds for the performance of the work, subject to additions and deductions by Change Order and subject to the Measurement and Payment Provisions, and subject to actual constructed quantities; the Total Contract Price of Two Million, seventy three thousand, five made to the Contractor on the basis of the Schedule of Unit Prices included as a part of his Bid, which shall be as fully a part of the Contract as if attached or repeated herein. F. Payments The Owner will make payments as provided in the General Conditions and Supplementary Conditions. G. Retainage SPECLIB021104 00520 -3 NAME OF PROJECT: First Streetscaoe Project, Sanford. Florida The value of each application for payment shall be equal to the total value of the Work performed to date, less an amount retained, and less payments previously made and amounts withheld in accordance with the General Conditions and Supplementary Conditions. Retainage for this project is 10 %, to be held by Owner as collateral security to ensure completion of Work. The Owner is not obligated to reduce retainage at any time during the Contract, but may choose to do so at its discretion once the Work is at least 75% complete. IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first above written. CONTRACTOR: Gomez Construction Company Name of Firm (Sig ature) Orlando Gomez, President Printed Name and Title ATTEST: By (Signature) Selma P. Gomez, Corporate Secretary Printed Name and Title The City of Sanford. Florida C ommunity Redevelopment Aoencv (CRA (SEAL) Name f Owner By (Signature) (SEAL) Printed Name and Title ATTEST: ,6 ig 6 e'V)4LM1 n C rn.utnVd Se(- L'I" Print Name and Title �J SPECLIB021104 00520 -4 NAME OF PROJECT: First Streetscaoe Project Sanford Florida \ 4 Q q § w � m / � W a A _ 4 0 ■ Q & § ° 7 @ R a o ) \ \ \ \ \ \ \ § % ) § E- / \ \ \ \ } C:) \ \ E* 5 j Cl) j § en § r Z m \\ 4 ! ) ) � ! / / 0 2 ) / / / f \ / \ ( } \_ > ) ) ) § ) ) \ 2 [ ]=E r}/ } } \ \ =1 \ \ \ j } ( § \ } j ) \\\ \ \\ \D § \ \y \\ \ � $ - F H o °q o c Cl qW Z O 0 (y MO 06 W W °° W N O O Wd rn O O O O F U n �a F W en 'y en W en ? r +� o e1G N .y .-i N M oz x �a a a a z � a U � � cn a w C7 O Q F a F y W W o c0 O O O W O O W C O W C x a x x a /Y O W F X U o� . ... z ... !'z 3 Z . c ' 3 z o c 3 z c) - a 3 U U D U � r 7 �A F c1D M V) V1 � V1 �n k � a u e k / w m w w § w z W a � Q a 0 ■ 06 � \ \ C) 00 00 00 C14 \§ { � f u \ \ \ \ \ � \ k \ ) / _ C4 ~ §Q Z \\ / § ± f f Q \ � Q E E § $ § § > \ / w w ® \ X22 /4 ° % m \ / 0 % / \ ( \ \ \ \ / \ \ ( \ \ § \\ \\2 \ \ H • A o W ° O O ^ O O O O r o O M N 00 try N H O N M M 00 to N W� W S M O 7 O O O a _ W E* 0t0 M 00 In N o a� �a a a a cn w w w � F cn z CA ¢ a F z ' z c a o 3 c c x o w as v .a o o z o q A a 3 v A > a > W W z fV N V W o w Q Q � q ^+ d• U N Q w E Q �i U O C c .D b c C a C •c7 �-1 > v W W" a x n 0.1 43 F o ? o s o o 0.' O 0 3 W O 3 W G 0 3 A u.5 z �"' GG y p„ p„C uc Y C� •� w z F a W F z �.� 3 G 3 x H F G�7 c5 Ccc7 ' rF. 3 3 cn �D N ti boa 1�1 F O as 3 A 0 x k a 4 u � Q § w � Q / m _ Q 0 4 z K p [ C> @ \ @ @ $ Cl \ / \ / \ k d\ �\ \ \ \ § \ \ \ / } �z en §k Z \\ \ ) G 4 a � \ 2 A \ 73 g = a ) q ) C \ ) / a [ ® = a z / r \ / w : w ) ) C\ \_\ \ \ ) \ \ _ } Q 3/ \ \ \ § \ \ \ z \ u \DU \ \cn //f / :D \/^ 2 fq en kn } / tn W 0. d U F WW F F W �z , A W ° o, o ° o, W o M N 00 7 W W ¢ � r- Cl) Cl) 0 o0 F U 0 0 0 0 0 v vQ rn v N W �{�. 7 ey � W 0 b M 0 ONO N M [- V n O F z �a a a a a a c U w w �+ � c a a a q p a o a a a A ;n y 7 iV G p � U W �� W C� W a a e b z v n w 3 , �"' U •C c U '� c U 'C c U � c C4 � G a w CD N M V F a O O O a a 7 k a u w § w � w / e z 0 4 z � / g \ / � 0 t / w 0 J I 2 /E 7 0 § \ \ \ } § w/ E � §[ \\ \ { ) ± § \ \ cn ) ( / \ , 3 ° \ / w ? & Z = 2 CD / \ } / — \ \ ) \ ) ) / f \ G / � ° E u = p =� ®) E ;— w & j \ @@ \ ; / / }j ) � � » m �c \ g 7 q / g \ / � 0 t / w 0 J I H ti a U A � FG x cn N v 00 F O F Pa w a U A � a d x W C) S W U a o CD 0 0 M M h F oz N x a� �a N E Q Q X L a b a w w o b cz w X b Qa n d C in b U x L O x L O cn N O cn coo x x cn N v 00 F O F Pa w a U A � a d x \ w � R WE 2 /\ $ § ( Oli �� a $ i $ - $� \ j \ e / \ 2 ( \ 2 / 2 2 til 4 u w / � k / � } Q d w \ 6 $ § \ \ \ § \ a , / o CD \ ( lzt } } CD CD _ rq CA Tr m \k $� _ ) ) � j \ \ : f § 3 \ c = ® j = / \ ( \ \\ _+§ = a /;[ 2;a}\ \/ \ :0 \ .4 /; / od % f ( $ § ( $ $ g F H W F F-1 F G A W ° O O O ° Cl o E" DC O 7 O N M O O o o p W U 0 . ° o ° o ° o ° o ° o ° o 0 0 o v r--: 6 0 z o H dW k F �z ap a d a z w w w W w W L 1--1 G 7 h V U d b w n > x x x U i 3 a 0 3 u 0 3 d 0 3 d p i W v 5 > c > v c v c > c a v c a v c ro U U ... U ._ m U ._ > S ._ F 3 3 3 3 3 a 3 a] 3 ] 0 5 z d GG U A d FO W I 1 I I I I a U F W W W F F W W W F H w F a F a F O w h w F w Fo g $ W d N W U P. g ° o F o C 0 z x g H tn E) a� a� �a z w w x 0 Q b x b Q z N o b = 3 cn W v d -- � A W � � . v �n a F O w h w F W a U H W a F H H F z 0 H N W FBI U W W J 8 C) O M °o S ° o E W C:) ° g o W a 8 ° ° e °o. 0 M M � W F� o-W� •-� kn W M M M C ti F N D oz x �a CA z CA a W a w C w d w w a d w 0 w Q > a L w a w a 0 w Q Q b u o Q w z a 7 o x x a I U a a a c > z 0 y s A G W L z x o c a o (3 s cn W 'a F 3 F 3 U F o 3 Q E= 3 � � c� � c v❑ z� � c (� � c I c a v c Q a a U a W w U a a w W z [� V w .F. r a 3 eq N O O en 1q rn MV.. en p b b b w a U E-� W a F F W �z �O 1--I N z U' U w W F-� W qq F z 0 0 0 0 0 0 0 ° o ° o, 0 F CD o W � �D •-- �D rV � N W U a F ° O ° 0 0 0 Cl ° o z � 00 H dW N a z dd w w z w w w w w c v Q y A > cn Oo F O W W O > U y ¢ cn w A y Q w v 3 E a Q a Q cn w a Z C vn U z W F W F a b W O a a U W O K O � 3 > O 3 O 3 C O 0 3 G 3 w y 0¢ = O W W x w w W 0 a .v, c A v c c a c > v❑ v c c a a` a W c It N O O O .w 00 z 0 F N z U w w v) N (V 00 0 N 6R a F O F i O F N z c� U w w s s q A z o o , F j W� v W U ° o a W F W M o a �a w .F. z 0 Q a z W n w a z' o o d F � U W F 0 w 0 3 H o v) N (V 00 0 N 6R a F O F i O F N z c� U w w s s a < u q k / z w k / z ■ \ 0 a w z \ w � 4 _ z \ _ § � IT, § / C) § /= o / o C \ \ \ \ §2 \ \ \ \ - - - z \\ cn z \ E \ \ \ 9 ; ; \ § \ \ § § § § ) ) j j ) j j up o g g ) ) ) ) r \ \ \ \ \ © \ / / »\ ) ) ^ ^\ ® ® ~ ~\ __ / A j » 7 I F�1 W y d C�7 z y y V O a r"1 N I Ib ywI cn 77 �o L C�7 ax � ax b°'x ro z o r M 0 z p N d O N t d � "I d I'/ti ICI 11 � 17 r4 rl lyI � V y l-II �/ V �l._yI VI 'Ml > Rl 1/ MJ Iy^ V, z� O O A y0 y y 0 z n A n 8 � O A 0 p O O O d I F�1 W y d C�7 z y y V O r / _ § 2 Q > § \ � �q \� m\ m� m w n x / « � tA � « 7y ® {m \o r <= E \ ] : \ � / } \ � \ \ _ z > /\ z� ~ ƒ _ CD _ / \ ( \ 22 e r / _ § 2 Q > § \ � �q \� m\ m� m w n x / 2 2 _ � 2 2 � § M _ \ ® \ � r � » � m n x } « « 3 « e ( w w - g ) & � ©«/ ® Q /\ ®0 ¥/ «/ 0 \\ \o \\ \ E \ { } � \ Q Q § G G G G Q Q w z > g §? x m 2 \ \ \ \ \ \ \ Cl §� § 2 2 _ � 2 2 � § M _ \ ® \ � r � » � m n x } 1�1 �I x y z z d c r� z y b O CA ci H O y Hf W W N W 00 Vi r x y z z y b ry y o 00 f [ f C-7: f .. Z. 0 ad n.d �b b i w b � a x aCl) � 5 V7 y � A Oil z y Aro w y0 cn y V V O O F�1 y r.i n 0 900 ° C:) H �y d r x y z z y b ry y Y z d n z d y x x y y y o z H z H f� Y b t� b CD 0 p n y 0 CD 0 o� H CrJ v� 0 0 N z Y z d n z d y x x y y y o z H z H f� Y b t� b CD 0 p n y 0 CD 0 m H CrJ Y z d n z d y x x y y y o z H z H f� Y b t� CD 0 n CD 0 O Cy H d Y z d n z d y x x y y y o z H z H f� Y b t� _ S ■ Q � m Q 4 w c ¥ 2 §E 0 §f C, \ � \ �z \� §k - z \\ § � Q § / k ) � k � � ) \ ] ®\ \\ / / THE AMERICAN INSTITUTE OF ARCHITECTS r] AIA Document A311 Bond No. 104 335 344 Performance Bond KNOW ALL MEN BY THESE PRESENTS: that (Here insert full name and address or legal the of contractor) Gomez Construction Company, 750,74ckson,4venue, `tMinter Part, EFlor7da 32789 as Principal, hereinafter called Contractor, and (Here insert full name and address or legal title of Surety) Travelers Casuafty andSurety Company ofAmerica; One 7owerSquare, 9'fartfvrd, Connecticut 06183 as Surety, hereinafter called Surety are held and firmly bound unto (Here insert full name and address or legal title of Owner) g1te City of Sanford, Tforida Community ERtdevefopment agency (C� 300 Forth EPark venue, from 326, Sanford, Tfonda 32771 as Obligee, hereinafter called Owner, in the amount of Tulo gtiffton TUV 9fundredEighty °Thousand Eight MundredEighty` woand23 /100 ($2,280,882.233) for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated (Here insert full name, address and description of project) , entered into a contract with Owner for glistoric first ,street Streetscape eject; Project No. I3 03 - 04125 in accordance with Drawings and Specifications prepared by (Here Insert lull name and address or legal title ofArchlteco which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA FEBRUARY 1970 ED • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 PERFORMANCE BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall promptly and faithfully perform said Contract, then this obligation shall be null and void; otherwise it shall remain in full force and effect. The Surety hereby waives notice of any alteration or extension of time made by the Owner. Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner having performed Owner's obligation thereunder, the Surety may promptly remedy the default, or shall promptly 1) Complete the Contract in accordance with its terms and conditions, or 2) Obtain a bid or bids for completing the Contract in accordance with its term and conditions, and upon determination by Surety of the lowest responsible bidder, or if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible bidder, arrange for a contract between such bidder and Owner, and make available as work progresses (even though there should be a default or a succession of defaults Signed and sealed this day of (Witness) I - under the contract or contracts of completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the contract price," as used in this paragraph, shall mean the total mount payable by Owner to Contractor under the Contract and any amendments thereto, less the amount property paid by Owner to Contractor. Any suit under this bond must be instituted before the expiration of two (2) years from the date on which final payment under the Contract falls due. No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named herein or the heirs, executors, administrators or successors of the Owner. ll4 Gomez Construction Company (Principal) Orlando Gomez, Jr., Vice President (Seal) Travelers Casualty and Surety Comoany of America (Surety) Charles D. Nielson, Attomey -In -Fact and Florida Resident Agent AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA FEBRUARY 1970 ED • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 Z Travelers IMPORTANT DISCLOSURE NOTICE OF TERRORISM INSURANCE COVERAGE On November 26, 2002, President Bush signed into law the Terrorism Risk Insurance Act of 2002 (the "Act "). The Act establishes a short -term program under which the Federal Government will share in the payment of covered losses caused by certain acts of international terrorism. We are providing you with this notice to inform you of the key features of the Act, and to let you know what effect, if any, the Act will have on your premium. Under the Act, insurers are required to provide coverage for certain losses caused by international acts of terrorism as defined in the Act. The Act further provides that the Federal Government will pay a share of such losses. Specifically, the Federal Government will pay 90% of the amount of covered losses caused by certain acts of terrorism which is in excess of Travelers' statutorily established deductible for that year. The Act also caps the amount of terrorism - related losses for which the Federal Government or an insurer can be responsible at $100,000,000,000.00, provided that the insurer has met its deductible. Please note that passage of the Act does not result in any change in coverage under the attached policy or bond (or the policy or bond being quoted). Please also note that no separate additional premium charge has been made for the terrorism coverage required by the Act. The premium charge that is allocable to such coverage is inseparable from and imbedded in your overall premium, and is no more than one percent of your premium. TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY Hartford, Connecticut 06183 -9062 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S) -IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies ") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Charles D. Nielson, Charles J. Nielson, Laura Lee Clymer, Mary C. Aceves, Warren M. Alter, David R. Hoover, of Miami Lakes, Florida, their true and lawful Attorney(s) -in -Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, the following instrument(s): by hislher sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duly authorized officers of the Companies, and all the acts of said Attorney(s)- in -Fact, pursuant to the authority herein given, are hereby ratified and confirmed. This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attomeys -in -Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's time and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attomeys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Power of Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attomeys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (05 -04) Unlimited IN WITNESS WHEREOF, TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY have caused this instrument to be signed by their Senior Vice President and their corporate seals to be hereto affixed this 12th day of July, 2004. STATE OF CONNECTICUT }SS. Hartford COUNTY OF HARTFORD NW Y Ary N 3 uRFry C � >Y HAnTFCRD, Deo S j �D ; TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY By George W. Thompson Senior Vice President On this 12th day of July, 2004 before me personally came GEORGE W. THOMPSON to me known, who, being by me duly sworn, did depose and say: that he /she is Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, the corporations described in and which executed the above instrument; that he /she knows the seals of said corporations; that the seals affixed to the said instrument are such corporate seals; and that he /she executed the said instrument on behalf of the corporations by authority of his/her office under the Standing Resolutions thereof. 0 0 My commission expires June 30, 2006 Notary Public Marie C. Tetreault CERTIFICATE I, the undersigned, Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, stock corporations of the State of Connecticut, DO HEREBY CERTIFY that the foregoing and attached Power of Attorney and Certificate of Authority remains in full force and has not been revoked; and furthermore, that the Standing Resolutions of the Boards of Directors, as set forth in the Certificate of Authority, are now in force. Signed and Sealed at the Home Office of the Company, in the City of Hartford, State of Connecticut. Dated this day of .20 . /YY g ,iyNN0 0 I.BU��' �v a�,� L a li4ATFt7 ''j 9 g j�' p (FN a S D; BY ... • F �J Peter Schwartz Senior Vice President Nielson, A [ter i ssoc tes, Inc. Bond Public Works Bond In compliance with Florida Statutes 255.05(1)(a) Bond No. 104 335 344 Contractor f�'omez Construction Company Address 750 Jackson Avenue Winter Park, Florida 32789 Phone No. (407) 6284353 Surety Company Travelers Casualty and Surety Company of America Address One Tower Square Hartford, Connecticut 06183 Phone No. (860) 277 -0156 Owner Name The City of Sanford, Florida Community Redevelopment Agency (CRA) Address 300 North Park Avenue, Room 236 Sanford, Florida 32771 Phone No. Contract/Project No. MB No. 03 - 04125 Project Name Yfistotic First Street .Streetscape PRj'6'Ct Project Location First Street, Sanford, Florida Legal Description There is no legal description per se as this for various and Street Address locations throughout The City of Sanford Description of Work streetscape project Front Page All other bond page(s) are deemed subsequent to this page regardless of any page number(s) that may be preprinted thereon. LABOR AND MATERIAL PAYMENT BOND NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the following conditions: 1. Claimant is defined as one having a direct contract with the Principal or with a Subcontractor of the Principal for labor, material, or both, used or reasonably required for use in the performance of the Contract, labor and material being construed to include that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly applicable to the Contract. 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein defined, who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such claimant's work or labor was done or performed, or materials were furnished by such claimant, may sue on this bond for the use of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any claimant: a) Unless claimant, other than one having a direct contract with the Principal, shall have given written notice to any two of the following: the Principal, the Owner, or the Surety above named, within ninety (90) days after such claimant did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with substantial Signed and sealed this day of accuracy the amount claimed and the name of the parry to whom the materials were furnished, o for whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail, postage prepaid, in an envelope addressed to the Principal, Owner or Surety, at any place where an office is regularly maintained for the transaction of business, or served in any manner in which legal process may be served in the state in which the aforesaid project is located, save that such service need not be made by a public officer. b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract, it being understood, however, that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law. c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state in which the project, or any part thereof, is situated, and not elsewhere. 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder, inclusive of the payment by Surety of mechanic's liens which may be filed of record against said improvement, whether or not claim for the amount of such lien be presented under and against this bond. ['�O/7' Gomez Construc . n Com (Seal) Orlando Gomez, Jr., Vice President Travelers Casualty and Surety Company of America D. Nielson, Attorney -In -Fact and Florida Resident Agent THU BOND HBRM 18 AMENDED 90 THIN THE Pppvgt10118 AIA LIMITATIONS OF SECTION 28A.07 OR SECTION 7171.27 FLORIDA STATUTES, W14ICNEVER IS APPLICAMS. ARE H100RPORATED HEREIN By REFERENCE. AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA FEBRUARY 1970 ED • THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y. AVE., N.W., WASHINGTON, D.C. 20006 4 travelers IMPORTANT DISCLOSURE NOTICE OF TERRORISM INSURANCE COVERAGE On November 26, 2002, President Bush signed into law the Terrorism Risk Insurance Act of 2002 (the "Act "). The Act establishes a short-term program under which the Federal Government will share in the payment of covered losses caused by certain acts of international terrorism. We are providing you with this notice to inform you of the key features of the Act, and to let you know what effect, if any, the Act will have on your premium. Under the Act, insurers are required to provide coverage for certain losses caused by international acts of terrorism as defined in the Act. The Act further provides that the Federal Government will pay a share of such losses. Specifically, the Federal Government will pay 90% of the amount of covered losses caused by certain acts of terrorism which is in excess of Travelers' statutorily established deductible for that year. The Act also caps the amount of terrorism - related losses for which the Federal Government or an insurer can be responsible at $100,000,000,000.00, provided that the insurer has met its deductible. Please note that passage of the Act does not result in any change in coverage under the attached policy or bond (or the policy or bond being quoted). Please also note that no separate additional premium charge has been made for the terrorism coverage required by the Act. The premium charge that is allocable to such coverage is inseparable from and imbedded in your overall premium, and is no more than one percent of your premium. TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY Hartford, Connecticut 06183 -9062 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S) -IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies ") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Charles D. Nielson, Charles J. Nielson, Laura Lee Clymer, Mary C. Aceves, Warren M. Alter, David R Hoover, of Miami Lakes, Florida, their true and lawful Attorney (s) -in -Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, the following instrument(s): by his/her sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duly authorized officers of the Companies, and all the acts of said Attorney(s)- in -Fact, pursuant to the authority herein given, are hereby ratified and confirmed. This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attomeys -in -Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Power of Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (05 -04) Unlimited IN WITNESS WHEREOF, TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY have caused this instrument to be signed by their Senior Vice President and their corporate seals to be hereto affixed this 12th day of July, 2004. STATE OF CONNECTICUT }SS. Hartford COUNTY OF HARTFORD �� � 9J' �TY ANO SL r orsa,�fr f ^ \r � p � t o o Q'PAW r i J. W ,� RQ � W H/J1rFORD, V' 1982 O TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY George W. Thompson Senior Vice President On this 12th day of July, 2004 before me personally came GEORGE W. THOMPSON to me known, who, being by me duly sworn, did depose and say: that he /she is Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, the corporations described in and which executed the above instrument; that he /she knows the seals of said corporations; that the seals affixed to the said instrument are such corporate seals; and that he /she executed the said instrument on behalf of the corporations by authority of his/her office under the Standing Resolutions thereof. 0 � p.TET � �► S My commission expires June 30, 2006 Notary Public Marie C. Tetreault CERTIFICATE I, the undersigned, Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, stock corporations of the State of Connecticut, DO HEREBY CERTIFY that the foregoing and attached Power of Attorney and Certificate of Authority remains in full force and has not been revoked; and furthermore, that the Standing Resolutions of the Boards of Directors, as set forth in the Certificate of Authority, are now in force. Signed and Sealed at the Home Office of the Company, in the City of Hartford, State of Connecticut. Dated this day of ,20 . y„vvb,q 8 ��pj Ji H4 o D; By Peter Schwartz Senior Vice President SECTION 00615 Bond No. 104 335 344 MATERIAL AND WORKMANSHIP BOND KNOW ALL MEN BY THESE PRESENTS: THAT WE g'C aeg Construction Lompany hereinafter referred to as "Principal' and Travelers Casualty and Surety Company of America hereinafter referred to as "Surety" are held and firmly bound unto 1) The City of Sanford , hereinafter referred to as the OWNER in the sum of ten percent (10 %) of the Contract Price as adjusted under the Contract Documents $ 228.088.22 for the payment of which we bind ourselves, heirs, executors, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has constructed certain improvements, including roadways, utilities, curbs, storm drains and other appurtenances in that certain Project described as 2) Dstot2C first ,Street StreetsCape Tmiect , and WHEREAS, the aforesaid improvements were made pursuant to an Agreement dated _ OWNER: and and filed with the Purchasing Office of WHEREAS, the Principal warrants and guarantees to the OWNER that all work, labor, materials, equipment and services furnished and performed has been done in a good and workmanlike manner and is of the highest quality, free from defects; and WHEREAS, Principal is obligated to protect the OWNER against any defects resulting from faulty Materials or Workmanship of said improvements and to maintain said improvements for a period of two (2) years from the date of Final Completion under the Contract Documents. NOW THEREFORE, the conditions of this obligation is such that if Principal shall promptly and faithfully protect the OWNER against any Defects resulting from faulty Materials and Workmanship of the aforesaid improvements and maintain said improvements for a period of two (2) years from the date of Final completion, then this obligation shall be null and void, otherwise it shall remain in full force and effect. 1) Name of Owner 2) Name of Project identified in Instructions to Bidders The OWNER shall notify the Principal in writing of any Defect for which the Principal is responsible and shall specify in said notice a reasonable period of time within which Principal shall have to correct said Defect. The Surety unconditionally covenants and agrees that if the Principal fails to perform, within the time specified, the Surety, upon thirty (30) days written notice from OWNER, or its authorized agent or officer, of the failure to perform will correct such Defect or Defects and pay the cost thereof, including, but not limited to engineering, legal and contingent costs. Should the Surety fail or refuse to correct said Defects, the OWNER, in view of the public interest, health, safety, welfare and factors involved, shall have the right to resort to any and all legal remedies 00615 -1 SPECLIB052803 against the Principal and Surety and either, both at law and in equity, including specifically, specific performance to which the Principal and Surety unconditionally agree. The Principal and Surety further jointly and severally agree that the OWNER at its option, shall have the right to correct said Defects resulting from faulty Materials or Workmanship, or, pursuant to public advertisement and receipt of Bids, cause to be corrected any Defects or said Defects in case the Principal shall fail or refuse to do so, and in the event the OWNER should exercise and give effect to such right, the Principal and the Surety shall jointly and severally hereunder reimburse the OWNER the total cost thereof, including, but not limited to, engineering, legal and contingent costs, together with any damages either direct or consequent which may be sustained on account of the failure of the Principal to correct said defects. IN WITNESS WHEREOF, this instrument is executed this the day of Gomez Construction Company ATTEST: Principal (Contractor) Secret (Princi B y (S ignature) Selma P. Gomez Typed Name (CORPORATE SEAL) (Witness to Principal) PftLA F�)AgSI Typed Name Orlando Gomez Jr. Vice President Typed Name and Title 750 Jackson Avenue Address Winter Park Florida 32789 City, State, Zip (407) 628 - 4353 (407) 645 2499 Telephone No, Facsimile No. ATTEST: As per attached Power of Attorney (Surety) Secretary Travelers Casualty and Surety Company of America Surety SPECUB052803 00616 -2 (407) 649 -2686 (866) 467 5469 Telephone No, Facsimile No. By: C�"'J.12- .off, Attorney -in -Fact Charles D. Nielson, Attorney -in -Fact and Florida Resident Agent Typed Name i ypeo Name Wi nes as to Surety Mary C. Aceves Typed Name 5979 Northwest 151 Street #105 Address Miami Lakes Florida 33014 City, State, Zip (305) 822 -7800 (305) 558 -9650 Telephone No. Facsimile No. NOTE: Date of the Bond must not be prior to date of Agreement. If CONTRACTOR is a joint venture, all venturers shall execute the Bond. If CONTRACTOR is Partnership, all partners shall execute Bond. IMPORTANT: Surety companies executing Bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State of Florida, unless otherwise specifically approved in writing by OWNER. ATTACH a certified Power -of- Attorney appointing individual Attorney -in -Fact for execution of Performance Bond on behalf of Surety. END OF SECTION SPECLIB052803 00615 -3 Travelers IMPORTANT DISCLOSURE NOTICE OF TERRORISM INSURANCE COVERAGE On November 26, 2002, President Bush signed into law the Terrorism Risk Insurance Act of 2002 (the "Act "). The Act establishes a short-term program under which the Federal Government will share in the payment of covered losses caused by certain acts of international terrorism. We are providing you with this notice to inform you of the key features of the Act, and to let you know what effect, if any, the Act will have on your premium. Under the Act, insurers are required to provide coverage for certain losses caused by international acts of terrorism as defined in the Act. The Act further provides that the Federal Government will pay a share of such losses. Specifically, the Federal Government will pay 90% of the amount of covered losses caused by certain acts of terrorism which is in excess of Travelers' statutorily established deductible for that year. The Act also caps the amount of terrorism - related losses for which the Federal Government or an insurer can be responsible at $100,000,000,000.00, provided that the insurer has met its deductible. Please note that passage of the Act does not result in any change in coverage under the attached policy or bond (or the policy or bond being quoted). Please also note that no separate additional premium charge has been made for the terrorism coverage required by the Act. The premium charge that is allocable to such coverage is inseparable from and imbedded in your overall premium, and is no more than one percent of your premium. TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY Hartford, Connecticut 06183 -9062 POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEY(S) -IN-FACT KNOW ALL PERSONS BY THESE PRESENTS, THAT TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, corporations duly organized under the laws of the State of Connecticut, and having their principal offices in the City of Hartford, County of Hartford, State of Connecticut, (hereinafter the "Companies ") hath made, constituted and appointed, and do by these presents make, constitute and appoint: Charles D. Nielson, Charles J. Nielson, Laura Lee Clymer, Mary C. Aceves, Warren M. Alter, David R Hoover, of Miami Lakes, Florida, their true and lawful Attomey(s) -in -Fact, with full power and authority hereby conferred to sign, execute and acknowledge, at any place within the United States, the following instrument(s): by his/her sole signature and act, any and all bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking and any and all consents incident thereto and to bind the Companies, thereby as fully and to the same extent as if the same were signed by the duly authorized officers of the Companies, and all the acts of said Attorney(s)- in -Fact, pursuant to the authority herein given, are hereby ratified and confirmed. This appointment is made under and by authority of the following Standing Resolutions of said Companies, which Resolutions are now in full force and effect: VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's time and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her. VOTED: That the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary. VOTED: That any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary, or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority. This Power of Attorney and Certificate of Authority is signed and sealed by facsimile (mechanical or printed) under and by authority of the following Standing Resolution voted by the Boards of Directors of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, which Resolution is now in full force and effect: VOTED: That the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any power of attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such power of attomey or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding upon the Company in the future with respect to any bond or undertaking to which it is attached. (05 -04) Unlimited IN WITNESS WHEREOF, TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY have caused this instrument to be signed by their Senior Vice President and their corporate seals to be hereto affixed this 12th day of July, 2004. STATE OF CONNECTICUT }SS. Hartford COUNTY OF HARTFORD MvW QTY Ary W qp SUgfIY 3�N O GA � sAarroR0.1 L� W HARTFORD, U' �1 9 S 2� O George W. Thompson Senior Vice President On this 12th day of July, 2004 before me personally came GEORGE W. THOMPSON to me known, who, being by me duly sworn, did depose and say: that he /she is Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, the corporations described in and which executed the above instrument; that he /she knows the seals of said corporations; that the seals affixed to the said instrument are such corporate seals; and that he /she executed the said instrument on behalf of the corporations by authority of his /her office under the Standing Resolutions thereof. 0 0 My commission expires June 30, 2006 Notary Public Marie C. Tetreault CERTIFICATE I, the undersigned, Senior Vice President of TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA, TRAVELERS CASUALTY AND SURETY COMPANY and FARMINGTON CASUALTY COMPANY, stock corporations of the State of Connecticut, DO HEREBY CERTIFY that the foregoing and attached Power of Attorney and Certificate of Authority remains in full force and has not been revoked; and furthermore, that the Standing Resolutions of the Boards of Directors, as set forth in the Certificate of Authority, are now in force. Signed and Sealed at the Home Office of the Company, in the City of Hartford, State of Connecticut. Dated this day of .20 . W.vW ��� ' J,.ITY ANO SC r r,A6U,� ` j a •' HpglFOfgl � a HARTFORD, i � 1 9 8 2 O By r��00NN J CONN. o q, i � �'` ry 't a °� � � h� TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA TRAVELERS CASUALTY AND SURETY COMPANY FARMINGTON CASUALTY COMPANY �p Peter Schwartz Senior Vice President • 750 Jackson Avenue Winter Park, Florida 32789 : 407 - 628 -4353 407 -645 -2499 fax Gomez Construction Company September 15, 2004 Mr. Tom George, Public Works Director City of Sanford, Florida P.O. Box 1788 Sanford, Florida 32772 Re: Historic Sanford First Street Project Hurricane Delays Dear Tom: Per our conversation we are requesting 15 additional calendar days be added to our contract for the affects of Hurricane Charley 5 calendar days, Utility delays 5 calendar days and Hurricane Frances 5 calendar days. The time loss included the preparation time for the events, the time lost associated with the delays the City Utility crews experienced due to the damages caused by the Hurricanes. • Hurricane Charley 8 -12 thru 8 -16 • Utility Delay 8 -17 thru 8 -21 • Hurricane Frances 9 -3 thru 9 -7 These inclement weather events required we safe up the area days prior the event and it took several days to recover after the events, costing us time and resources. We are requesting a no cost change order be processed for this time. Please see the attached forms for your execution. Sincer Robert E. LVy Branch Ma General Contractors and Construction Managers SECTION 00850 CHANGE ORDER FORM Change Order No. ONE Project Title Bid No. Owner: ( nn �F� 2177 ( CAF Z4> Contractor: ME ' Smuc - nC>NCo►uponw� Agreement Date: 3 I Z00 This Change Order is necessary to cover changes in the work to be performed under this Agreement. The GENERAL CONDITIONS, SUPPLEMENTARY CONDITIONS, and STANDARD SPECIFICATIONS apply to and govern all work under this Change Order. THE FOLLOWING CHANGES ARE MADE TO THE CONTRACT DOCUMENTS: (1) Original Contract Price (2) Current Contract Price (Adjusted by Previous Change Orders) (3) Total Proposed Change in Contract Price (4) New Contract Price (Item 2 + Item 3) (5) Original Contract Time (6) Current. Contract Time.(Adjusted by Previous Change Orders) (7) Total Proposed Change in Contract Time (8) New Contract Time (Item 6 + Item 7) , (9) Original Contract Substantial Completion Date (10) New Contract Substantial Completion Date 00850 -1 $ 2, o :? 3 , 5 - oct , ° $ - C�> - $2,O:iL3,S2 3° l 1 Days I:� I Days 115 Days I R& Days r>- 31.2CC>y 1 S", Z6� SPECLIBI20902 CHANGES ORDERED ITEM 1 Description of Change: upatE (f jO4 , Y t Q prr ti oVf�`f Reason for Change: fjk,(S Change in Contract Price: At d .° Change in Contract Time: ! j C - bA�f S ITEM 2 II ^ Description of Change: Reason for Change: 0 Change in Contract Pricer Change Contract Time: RCN `{S ITEM 3 Description of Change: t U9.NCA+4E ' F �t-" 5 Reason for Change: bELA Change in Contract Price: 4r o.' Change in Contract Time: S S - G' - ITEM 4 Description of Change: Reason for Change: Change in Contract Price: Change in Contract Time: 00850 -2 SPECLIB120902 ITEM 5 Description of Change: Reason for Change: Change in Contract Price: Change in Contract Time: CHANGE ORDER SUMMARY No. Description Change in Contract Price Change in Contract Time 1 c. E CAkQXfiJ d $' 2 ur `b O 3 4 5 TOTAL $ Da y; WAIVER This Change Order constitutes full and mutual accord and satisfaction for the adjustment of the Contract Price and Contract Time as a result of increases or decreases in cost and time of performance caused directly and indirectly from the change. Acceptance of this Waiver constitutes an agreement between OWNER and CONTRACTOR that the Change Order represents an equitable adjustment to the Agreement and that CONTRACTOR shall waive all rights to file a Contract Claim or claim of any nature on this Change Order. Execution of this Change Order shall constitute CONTRACTOR's complete acceptance and satisfaction that it is entitled to no more costs or time (direct, indirect, impact, etc.) pursuant to this Change Order. APPROVAL AND CHANGE ORDER AUTHORIZATION ACKNOWLEDGMENTS The aforementioned change, and work affected thereby, is subject to all provisions of the original Agreement and specifically changed by this Change Order; and 00850 -3 SPLCL16120902 It is expressly understood and agreed that the approval of the Change Order shall have no effect on the original Agreement other than matters expressly provided herein. ATTEST: Contractor (S cretary) Printed Na I Officer Date By (Signature) S � (Corporate Seat) Date ATTEST: C o c Owner (Signature) Printed ame ' nd Title J-1 - 7-40 j Date By (Signature) `1��1�y (Seal) Date �— END OF SECTION 00850 -4 SPECLIB120902